Greening construction contract

Greening construction contract, the contract can protect everyone's interests from damage to the maximum extent, but many people lose the legal binding force of the contract because of the wrong content signed, making their own interests irreparable. Let's look at the greening construction contract.

Greening construction contract 1

Employer: _ _ _ _ _ _ _ Company (hereinafter referred to as Party A)

Contractor: _ _ _ _ _ _ _ _ (hereinafter referred to as Party B)

In accordance with the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and relevant regulations, and in combination with the specific conditions of this project, this contract is hereby signed by both parties through consultation for their compliance.

Article 1 General situation of the project

1. Project name: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

2. Project location: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _;

3. Scope and content of project contracting: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ If the construction of this project is contracted by Party B, Party B will provide this service free of charge. If Party B does not undertake the construction of this project, Party A shall pay Party B the service fee of _ _ _ _ _ _.

4. Contracting method: Party B contracts projects, materials, machinery, management, quality, construction period, safety, taxation, civilized construction, deepening and optimizing design, etc.

Article 2 Project duration

1. The commencement date of this project is subject to the commencement notice of Party A and confirmed by Party B, and the completion date is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

2. Under any of the following circumstances, the construction period shall be postponed accordingly after being signed by the on-site supervision engineer or engineering representative of the Employer, and the postponed construction period shall be determined in writing.

(1) The Employer cannot hand over the contractor's main construction site, access roads and construction water and electricity _ _ _ days before the commencement date stipulated in the contract, which will affect the contractor's construction site;

(2) It is clear that the materials, equipment, finished products or semi-finished products supplied by the Employer fail to enter the site at the time agreed by both parties, or the materials, equipment, finished products or semi-finished products entered the site are found to have staged defects when submitted to the Contractor for inspection, and need to be repaired, modified, replaced or replaced, thus delaying the construction progress;

(3) During the construction process, water supply and power failure continued to affect for more than _ _ _ _ _ hours;

(4) The employer's on-site supervision engineer or engineer's representative delays the visa formalities, which affects the builder of the next working procedure;

(5) Failing to allocate the advance payment, project progress payment and price difference of purchased materials as stipulated in the contract, which affects the construction progress;

(6) The progress of the project is affected by natural disasters (such as typhoons, floods, fires and earthquakes caused by natural causes). ) is irresistible to mankind;

(7) Major design changes occur.

Article 3 Project contract cost:

1. The budgeted contract cost of this project is RMB _ _ _ _ _ _ _, that is, RMB _ _ _ _ _ _.

2, according to the eighth standard according to the actual amount of settlement.

Article 4 Supply and Inspection of Materials and Equipment

1. Imported special materials shall be provided by the owner to the site or designated place. If the goods are delivered outside the designated delivery place, the party awarding the contract shall be responsible for the over-distance freight and other expenses;

2. Complete sets of equipment and special equipment shall be delivered to the contractor after bidding, ordering, supply and commodity inspection. The equipment that arrives in advance shall be kept by the Employer and delivered to the Contractor for safekeeping during installation, and shall not be misappropriated, lost or damaged.

3. All materials, equipment, finished products and semi-finished products shall be accompanied by certificates.

4. If unqualified materials are found, the supplier must transport them out of the field quickly.

5. If the building materials, equipment and the contractor with certificate have any objection to the inspection, they can be reinspected. If the products pass the inspection, the inspection expenses shall be borne by the employer who requires the inspection; If the product is unqualified, the inspection fee shall be borne by the contractor.

6. The contractor shall not use building materials, equipment and components. Without qualification certificate and without inspection or appraisal.

7. If Party A changes the materials reserved or purchased by Party B, Party A shall bear the losses caused thereby.

Article 5 Project Quality and Inspection and Acceptance

1, the engineering quality requirements are excellent;

2, the contractor must be in strict accordance with the drawings, documents and relevant codes and regulations issued by the state, and accept the supervision and inspection of the employer's site supervision engineer or engineer representative;

3. The on-site supervision engineer employed by the Employer is _ _ _ _ _ _ _ _ _ _;

4, the contractor shall, according to the progress of the project, timely provide technical information about the quality of the project, such as materials, equipment certificate, material substitution must be approved by the design unit and the developer signature rear can use.

5. After the concealed works are self-inspected by the contractor, fill in the concealed works acceptance form and notify the on-site supervision engineer or engineer representative for inspection and acceptance. The supervision engineer or engineer's representative shall go to the site for inspection within 24 hours after receiving the notice, and the next working procedure can be carried out only after the visa is approved.

6, project completion acceptance, should be based on construction drawings, drawings, technical disclosure minutes, design change notice, construction acceptance specifications and quality inspection standards issued by the state.

7. After the completion of the project, the contractor shall provide complete technical files as required, and issue a completion notice. The acceptance time shall be determined by both parties through consultation, and the Employer shall organize relevant units to carry out the completion acceptance. After the acceptance, both parties sign the completion acceptance certificate and hand over the project to the employer for management.

8. The completed and unaccepted projects shall be kept by the contractor before completion.

9. After the project is handed over for acceptance, the warranty period of garden construction project is 1 year, and the warranty period of water and electricity is 2 years. During the warranty period, the damage caused by the construction quality shall be borne by Party B, the greening project shall be maintained for 6 months, and the maintenance water fee shall be borne by the Employer. In case of engineering quality problems caused by construction, the Employer shall notify the Contractor in writing and fix them at the appointed time. The contractor shall make repairs within 7 working days.

Article 6 Changes in construction design

1. The design drawings, descriptions and relevant technical data delivered by the Employer are effective basis for construction, and the Contractor shall not modify them without authorization.

2, major changes in the construction drawing, must be approved by the employer, the design unit, and _ _ _ days before the modification of the design modification agreement. The design change agreement can only be implemented by the contractor after it is signed by the employer. The agreement and the revised drawings will serve as supplementary documents to the contract.

3. When the revised drawings belong to design errors, equipment changes, structural changes, standard improvement, technical changes, and geological conditions are inconsistent with the actual design, the responsible party shall be responsible for the increased costs (including actual losses such as rework losses, shutdown, slowdown, relocation of personnel and mechanical equipment, and overstock of materials and components) and adjust the contract costs.

4. On the premise of ensuring the engineering quality and not lowering the design standard, the contractor puts forward reasonable suggestions for modifying the design, which will be implemented after being approved by the employer, the design unit or the relevant technical department;

5. When one of the following circumstances occurs in the construction process, the contractor must immediately notify the employer in writing and ask for confirmation;

(1) The design drawings and description documents are inconsistent with the conditions of the project site, and the' construction conditions' indicated in the design documents are inconsistent with the actual situation;

(2) The design drawings and documents are unclear or have errors and omissions, and the drawings are inconsistent with the specifications;

(3) Unexpected special difficulties occurred in the construction conditions not specified in the design drawings and description documents.

(4) The confirmed facts must be solved within 2 days. In case of shutdown due to failure to solve the problem on schedule, the loss of construction period shall be borne by the employer.

Article 7 Matters for both parties.

1, employer

(1) Handling land acquisition, young crops, tree compensation, cemetery relocation, house demolition and obstacle removal (including overhead and concealment), and providing relevant information on concealment and obstacles;

(2) Do a good job of "three links" before construction; According to the approved construction organization design or construction scheme, provide water and electricity connection points not more than _ _ _ _ meters away from the building in the red line diagram, and install water and electricity meters, so that the contractor can charge by the meter;

(3) According to the water supply, power supply, water pressure and voltage in the construction area, take measures to meet the needs of construction water and electricity;

(4) Provide the construction site as required;

(5) Within _ _ _ _ days after signing the contract (subject to receiving the last drawing), provide _ _ _ sets of complete construction technical data to the contractor;

(6) Determine the positioning piles, leveling points and coordinate control points of roads, lines and sewers of buildings (structures);

(7) Organize contractors and design units to participate in the disclosure of construction drawings, and make disclosure minutes signed by the three parties, and distribute them to relevant units within _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

(8) Review the progress of the contractor and pay the progress payment to the contractor in time;

(9) The supervision engineer or engineer's representative stationed at the construction site shall supervise and inspect the progress, quality, concealed works and contract implementation, and be responsible for handling design drawings, design change visas, intermediate acceptance of projects, progress payment visas and other necessary visas.

(10) Organize the project completion acceptance, and cooperate with the contractor for completion settlement according to the date stipulated in the contract.

2. Contractor

(1) Level the construction site, and build water, electricity, roads and temporary facilities within the construction battery limit;

(2) Prepare the construction organization design (or construction scheme), the general construction schedule, the mobilization plan of materials, equipment and finished products and semi-finished products, the water and electricity use plan, the completion notice, and the acceptance sheet of concealed works. , and send it to the employer and relevant units in time;

(3) Purchasing, supplying and managing materials and equipment according to the scope of division agreed by both parties;

(4) Carry out the construction in strict accordance with the construction drawings and specifications, ensure the quality of the project, and complete the delivery as scheduled according to the time stipulated in the contract;

(5) Responsible for site maintenance and cleaning before project completion;

(6) Provide technical data for completion acceptance, handle project completion settlement and participate in completion acceptance;

(7) During the warranty period stipulated in the contract, the contractor shall be responsible for repairing the engineering quality problems that belong to the contractor's responsibility for free.

Article 8 Payment and settlement of project price

1. Pay _ _ _% of the total project contract price within ten working days after signing the contract;

2. When Party B completes _ _ _ _% of the contract project amount, Party A shall pay _ _ _ _ _% of the total contract price as the progress payment within ten working days after receiving Party B's project payment application report;

3. After the project is completed, Party A shall pay _ _ _ _% of the total contract price as the progress payment within ten working days after receiving Party B's project payment application report;

4. After the acceptance of the project, Party A shall complete the audit of the project settlement within 30 days after receiving Party B's statement ... and pay _ _ _ _% of the total settlement price within seven days after the project settlement; Leave the balance payment of 5% of the settlement price, and pay it to the contractor within _ _ _ _ days after the expiration of the single warranty period of the garden construction project and the greening project respectively.

5. If the Employer defaults on the progress payment or the final payment, it shall be handled according to the relevant regulations of the bank on overdue payment.

6. If the contractor stops working or slows down due to the employer's default on the project payment and poor payment of purchased materials, it shall be borne by the employer.

7. The project price settlement method should be handled according to the following conditions:

7. The quantities of1are based on the actual quantities, such as the construction drawings being audited, the visa changed and the records of the blue prints.the design.

Perform calculations;

7.2 The cost of landscaping works is calculated according to the comprehensive quota of landscaping works in Guangdong Province in 2003.

7.3 The installation cost is calculated according to the comprehensive quota of installation project in Guangdong Province in 2002.

7.4 The settlement fee for landscaping works shall be calculated by 5% of the total price after charging in the Quota Valuation Table for Landscape Works in 2003 issued by _ _ _ _ _ _ _ _ Construction Engineering Cost Management Station on July, 2003 12; The settlement fee of hydropower installation project shall be calculated by 5% of the total price after charging in the Quota Valuation Table of Installation Project in 2003 issued by _ _ _ _ _ _ _ _ _ _ _ _ _ _ Construction Project Cost Management Station on July, 2003 12.

7.5 The prices of main materials for landscape architecture, greening engineering and installation engineering shall be subject to the Price List of xxx Construction Engineering, Installation Engineering, Landscaping Engineering Materials and Seedlings issued by Dongguan Construction Committee in July 2004. The employer may specify the brand, manufacturer, place of origin and price of certain materials and seedlings.

7.6 The materials specified by the Employer or the specified price shall be included in the independent expenses at the time of settlement, and the price shall not be reduced according to Article 8.7.4 of this contract.

Article 9 Liability for breach of contract

1, contractor's responsibility

(1) If the project quality is not in conformity with the contract, it shall be responsible for free repair or rework.

(2) If the delivery time of the project is not in conformity with the regulations, Party B shall pay Party A RMB _ _ _ _ _ _ _ _ _.

2, the employer's responsibility

(1) fails to perform its responsibilities as stipulated in the contract, and the completion date will be postponed.

(2) If the project has not been accepted, the Employer uses it in advance or without authorization, and the quality or other problems arising therefrom shall be borne by the Employer.

Article 10 Ways to settle disputes

In case of any dispute during the execution of this contract, both parties shall settle it through consultation in time. If negotiation fails, either party may directly bring a lawsuit to the people's court of _ _ _ _ _.

Article 1 1 Special Terms and Conditions

Under special circumstances, if there are any matters not covered in the terms of this contract, both parties may negotiate special terms according to specific conditions and relevant regulations.

Article 12 Supplementary Provisions

Matters not covered in this contract shall be implemented in accordance with the Contract Law of People's Republic of China (PRC) and relevant regulations.

Appendix to the contract: all construction drawings. The above annexes are an integral part of this contract and have the same legal effect.

This contract shall come into effect after being signed and sealed by both parties. After the completion of the whole contract project, the inspection shall be conducted and the balance of the project shall be settled. After the warranty period, it will naturally expire.

The Contract is made in two originals, of which the Employer 1, the Contractor 1 and two copies, the Employer 1 and the Contractor 1.

Employer (seal) _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Legal representative (signature): _ _ _ _ _ _ Legal representative (signature): _ _ _ _ _ _ _

Authorized representative (signature): _ _ _ _ _ _ Authorized representative (signature): _ _ _ _ _ _ _

Date of signing: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Greening construction contract 2

Party A entrusts Party B to implement the greening project. In order to clarify the responsibilities, obligations and rights of Party A and Party B in this project, and to ensure the quality and quantity and complete the project construction tasks on schedule. Through negotiation, Party A and Party B hereby sign the following contract terms:

Article 1: Project Location and Name:

1. Project location:.

2. Project name: Greening project on both sides of the east section of national highway.

Article 2: The following documents shall be regarded as an integral part of this contract. Namely:

1. Other agreements signed by Party A and Party B during the execution of this contract.

2. Drawings and bill of quantities: The greening design scheme and bill of quantities provided by Party A shall prevail. ..

3. Negotiations, changes and written agreements or documents between the two parties on this project shall be regarded as an integral part of this contract.

Article 3: Signing method:

1. Contract content: greening construction.

2. Contracting methods: contracting work, contracting materials, contracting quality, contracting period, maintenance, contracting survival rate and contracting safety.

3. Project cost: The contract is signed according to the bid price (RMB) (with bill of quantities attached), and the unit price of seedlings is guaranteed at one time. After the completion acceptance, calculate the engineering quantity according to the actual situation.

4. Engineering changes during construction: subject to the visa of Party A's representative, and adjusted according to the facts.

Article 4: Commencement and Completion Date: This project is from year to year.

Article 5: Project Quality and Safety:

1. The construction, inspection and evaluation of engineering quality are based on relevant technical specifications and quality inspection and evaluation standards, standards, specifications and related technical documents: Provincial Construction Committee document Su Jianyuan (XX) No.204, Technical Specification for Garden Plant Planting in Provincial Cities (Trial), Technical Specification for Garden Plant Maintenance in Provincial Cities (Trial), Unified Standard for Construction Quality of Building Projects, etc.

2. Party B must carry out the construction in strict accordance with the construction drawings, specifications and construction operation procedures to ensure the quality and safety.

3. Party B shall actively and seriously prepare the construction plan, and submit it to Party A for approval before the commencement date, and organize the construction according to the construction plan confirmed by Party B to ensure the smooth completion of the project.

4. The design changes can only take effect after being signed and approved by Party A, and Party B should be familiar with the drawings carefully and strictly implement the relevant standards.

5, seedling digging, loading and unloading, transportation, stacking in strict accordance with the operating specifications.

6. Pay special attention to the quality control of pond opening, planting and watering in the process of planting.

Article 6: Requirements for organizing material supply:

1. All seedlings are supplied by Party B, and the seedlings entered by Party B meet the requirements of variety, specification, quantity and quality, and can only be used after being approved by both parties.

2, seedling approach quickly comes into play according to the construction progress plan.

Article 7: Payment of Project Price:

1. Project price support: 50% of the total project price will be paid after the project is completed and accepted, 30% of the total project price will be paid before the end of the year and% of the total project price will be paid before the end of the year.

2. Settlement of project price: the project price is based on the actual engineering quantity.

Article 8: Project Completion Acceptance and Defects Liability Period:

1, project completion acceptance, should be based on construction drawings and instructions.

2. Before the project is completed, Party B shall organize self-inspection.

3. Within 10 days after receiving Party B's project completion report, Party A shall organize relevant units to conduct completion acceptance.

Article 9: Supplementary provisions:

1. This project contract shall come into effect after being signed and sealed by Party A and Party B, and the project defect liability expires, and all the projects are completed and accepted, and the project price will become invalid after settlement.

2. During Party B's construction, Party A shall provide all convenient conditions for the construction, such as electricity, water and coordination of local conflicts.

3. Defects liability period: The defects liability period of this contract is one year after the completion acceptance.

4. During the defect maintenance period, the contractor shall do a series of maintenance management work in time, such as cleaning, weeding, fertilizing, pest control, pruning, watering and wetting, replanting, etc. To ensure a 98% success rate.

5. During the defect maintenance period, in case of car crush, intentional damage and personnel theft, all matters shall be solved by Party A with the assistance of Party B, and the expenses shall be paid by Party A in one lump sum.

6. Matters not covered in this project shall be determined by both parties through consultation.

7. This project is made in duplicate, with Party A and Party B holding one original and one copy/copy respectively.

Party A: Party B:

Representative of Party A: Representative of Party B:

Date of signature: year month day.

Greening construction contract 3

Owner (Party A):

Contractor (Party B):

In accordance with the Contract Law of People's Republic of China (PRC) and relevant national laws and regulations, Party A and Party B, on the basis of equality, voluntariness, equal compensation, fairness, honesty and credit, have reached an agreement on Party A's entrustment of Party B to carry out the construction project through friendly negotiation, and hereby sign this contract.

Article 1: Project Overview

1, project name:

2. Project location:

3. Scheduled commencement date: YY.

Article 2: Scope of Construction

1, construction scope:

Backfill planting soil shall be settled according to the actual quantities on site and approved by the representatives of both parties, but the unit price shall not exceed the budgeted unit price limit approved by Party A. ..

Article 3: Construction Method

1. This project is implemented by Party B in the form of contract work and materials.

Article 4: Construction Period

1. The construction period starts from the planned commencement date to the date when Party B completes the project and passes all the acceptance stipulated in the contract, which is estimated to be days (including legal holidays), excluding the time when Party B waits for Party A's acceptance after notifying Party A of the acceptance.

2. In case of any of the following circumstances, Party B shall notify Party A in writing within 2 days after the visa reason occurs, and the construction period will be postponed accordingly after the visa is issued by the representatives of Party A and Party B. Otherwise, it will be deemed that Party B has waived the right to obtain the visa, and the project will not be postponed.

(1) The project construction progress is affected by Party A's reasons, such as not handing over the site on time, connecting water and electricity, and changing the design by Party A, etc.

(2) Force majeure factors.

Article 5: Project Quality and Acceptance Criteria

1. The project quality must be qualified (the acceptance standard shall be implemented according to the design requirements of the owner and the industry norms). If the project fails to be settled on time or submitted for acceptance due to Party B's deliberate delay, the project cannot be assessed as qualified.

2. The quality of seedlings provided by Party B must be controlled in advance, and seedling size should be selected in strict accordance with the design requirements, and the planting quality of seedlings must be strictly in accordance with the greening planting specifications.

3. The seedling survival rate reached 100%.

4. After the project is completed, Party B shall notify Party A for acceptance. Both parties shall inspect the project quality on site, and Party A shall sign it for approval after it is qualified.

Article 6: Project Price and Settlement Payment Method

1. The total project budget is RMB (in words).

2. Settlement method:

(1) Party A shall pay Party B 30% of the total project budget price in advance within working days before the planned commencement date;

(2) Within working days after Party B's materials and workers enter the site and submit the commencement report, Party A shall pay Party B 30% of the total project budget;

(3) Within working days after Party A and Party B handle the completion acceptance settlement procedures, Party A shall pay Party B an additional 90% of the total project settlement.

(4) 10% of the total project settlement shall be used as the project quality deposit and maintenance fund. Within working days after the end of the maintenance period, Party A shall re-check with Party B on site and handle the maintenance termination procedures. Party A shall settle accounts with Party B after deducting all kinds of money and liquidated damages payable by Party B during the maintenance period according to this contract.

(5) The above payment methods are all forms of payment.

Article 7: Maintenance Period

1, and the seedling maintenance period is months, counting from the date when the construction of this project is completed and all the acceptance stipulated in the contract is qualified.

2. During the maintenance period, Party B shall unconditionally maintain any quality problems caused by Party B's construction within days from the date of receiving Party A's notice, and the seedlings that cannot survive shall be replaced in time. Otherwise, Party A has the right to send another construction team to carry out construction and maintenance, and all expenses will be deducted from the maintenance fund, and Party A has the right to claim compensation from Party B for the part exceeding the maintenance fund.

Article 8: Obligations of both parties

1, obligations of Party A.

(1) Appoint the site representative to be responsible for the overall management of the project construction.

(2) Provide Party B with construction site, ensure smooth transportation roads, and provide water and electricity for construction (water and electricity charges shall be borne by Party A).

(3) Provide the construction drawings of this project, and be responsible for organizing the blue prints.the design and design disclosure.

(4) After receiving the completion settlement book and complete completion settlement data submitted by Party B, Party A shall notify Party B to check the project price within two weeks and complete the settlement within two months after the completion acceptance.

2. Party B's obligations

(1) Appoint the site representative to be responsible for the overall management during the construction period.

(2) According to the construction drawings confirmed by Party A, complete the construction work within the contracted scope as agreed in this contract.

(3) Carry out safety construction in accordance with relevant safety laws and regulations, abide by the relevant provisions of Party A's construction site management, and undertake safety responsibilities such as fire prevention, theft prevention and accident prevention during construction. In case of safety problems, Party B shall bear the responsibilities. ..

(4) Before the project is delivered to Party A, be responsible for the protection of the completed project. During this period, if there is any damage, Party B shall repair it at its own expense and deliver it to Party A as agreed in the contract. If the construction period is delayed, it shall be handled according to the overdue completion clause in the liability for breach of contract.

(5) Party B shall ensure that the project quality reaches the acceptance standard.

(6) Party B shall submit the completion settlement book and complete completion settlement information to Party A within two weeks after the project completion acceptance, and check the project price with Party A within two months after receiving the notice of checking the project price sent by Party A. ..

Article 9: Liability for breach of contract

1. If the construction period is delayed due to changes in Party A's quantities or drawings, the completion date will be postponed.

2. If Party A fails to carry out the completion inspection and acceptance as agreed in this contract, Party A shall bear the project custody and risk responsibility.

3. If Party A fails to pay in time, so that the construction cannot be carried out, Party B may stop the construction.

4. If the project quality fails to meet the agreed standards, Party B shall bear the corresponding responsibilities.

5. During the construction, Party B shall not stop work for any reason except for force majeure or Party A's reasons. If the work is stopped for more than two working days without the above reasons, Party A shall terminate the contract, and Party B shall compensate Party A for the delay in construction period or other losses.

6. The liquidated damages payable by Party B to Party A shall be deducted from the unpaid amount by Party A.. If the liquidated damages are not enough to make up for Party A's losses, Party A may continue to claim compensation from Party B. ..

Article 10: Assignment clause

Without the written consent of both parties, neither party may unilaterally transfer its rights and obligations under this contract in whole or in part.

Article 1 1: Termination of the Contract

1, terminated due to dissolution

(1) Due to Party B's breach of contract, this contract cannot be performed or fully performed. If Party A considers it unnecessary to continue to perform this contract or Party B fails to correct its breach of contract after receiving the notice from Party A asking it to correct its breach of contract, Party A has the right to send a written notice to Party B to terminate this contract, which will take effect when it is delivered to Party B, and Party B shall be liable for breach of contract according to this contract. If the liquidated damages are not enough to make up for Party A's losses, Party A may continue to claim compensation from Party B. ..

(2) Due to Party A's breach of contract, this contract cannot be performed or fully performed. If Party B considers it unnecessary to continue to perform this contract or Party A fails to correct its breach of contract after receiving Party B's notice to correct its breach of contract, Party B has the right to terminate this contract by sending a written notice to Party A, and this contract shall come into effect when it is delivered to Party A, and Party A shall pay Party B the quantities confirmed by both parties according to the provisions of this contract and bear the liabilities for breach of contract.

(3) If one party of the contract exercises the right of rescission according to this contract, this contract shall be terminated from the date when the notice of rescission is served.

(4) After the termination of the contract, one party shall not be prevented from being held liable for breach of contract.

2. In any of the following circumstances, the contractual rights and obligations shall be terminated:

(1) The contract has been fulfilled as agreed;

(2) The Contract is terminated by consensus of all parties;

(3) In this contract, due to one party's violation of Article 1 of this article (including one party's unauthorized transfer of rights and obligations under this contract), the other party issues a notice to terminate the contract;

(4) Other termination circumstances stipulated by laws and regulations.

Article 12: Applicable legal provisions

The conclusion, validity, interpretation, performance and dispute settlement of this Contract shall be governed by the laws of People's Republic of China (PRC).

Article 13: Settlement of disputes

All disputes arising from or in connection with the execution of this contract shall be settled by all parties to the contract through friendly negotiation; If negotiation fails, either party may bring a lawsuit to the people's court with jurisdiction.

Article 14: Other

1. For matters not covered in this contract, both parties shall negotiate amicably and sign a supplementary agreement. The supplementary agreement has the same legal effect as this contract.

2. The annexes to this contract are an integral part of this contract and have the same legal effect as this contract.

3. This contract and its supplementary agreement shall come into effect as of the date of signature and seal by both parties, and shall automatically terminate upon the expiration of the maintenance period and the settlement of the balance.

4. This contract is made in duplicate, each party holds one copy, and each copy has the same legal effect.

Party A: Party B:

Address: Address:

Legal representative:

(or authorized contractor): (or authorized contractor):

Date: Date:

Complaint supervision telephone: Complaint supervision telephone: