Project Agreement

Nowadays, the use of letters of agreement has become the norm in daily life, and letters of agreement play a positive role in the performance of affairs between both parties. Does anyone know the format of the agreement? The following are 4 project agreements that I have compiled for everyone for your reference. I hope it can help friends in need. Project Agreement Part 1

Party A:

Legal representative:

Contact number:

Party B:

Legal representative:

Contact number:

Risk warning

There are various ways of cooperation, such as jointly establishing a company, jointly developing software, and jointly purchasing and selling Products, etc. Different cooperation methods involve different project contents, and the corresponding agreement terms may be different.

The terms of this agreement are based on specific projects and are for reference only. In practice, the terms need to be modified or re-drafted based on the actual cooperation methods, project content, rights and obligations of both parties.

This contract is based on the "______" beauty project between Party A and Party B on the basis of fairness, integrity, equal cooperation, and mutual benefit. In accordance with the provisions of the "Contract Law of the People's Republic of China", The following agreement has been reached, and both parties must abide by it.

1. The cooperation and operation agreement between the two parties is as follows:

Risk warning

The rights and obligations of the cooperation parties should be clearly agreed to avoid wrangling in the actual operation of the project. situation.

Warm reminder again: Due to the inconsistency in cooperation methods and project content, the rights and obligations of each party are also inconsistent, and should be drafted based on the actual situation.

1. Party A provides its own business premises _________ free of charge and cooperates with Party B in operations.

2. Party A shall provide hardware and software equipment suitable for the cooperative operation of both parties.

3. Party A will introduce Party B’s treatment projects into Party A’s business premises for cooperation in accordance with the cooperation operation specifications of this contract.

4. Both parties should provide each other with professional knowledge guidance and training to facilitate cooperation and promotion.

5. Party B selects an excellent operation team to station at Party A’s own business premises from the effective date of the cooperation contract, abide by this cooperation operation system, standardize operation management, and assign a dedicated person to be responsible for coordination between the two parties. and communication, it is necessary to closely integrate the cooperation between the two parties and implement the management system. In addition to the team, Party B must maintain a quota of ______ support personnel to flexibly support Party A in on-site execution of business at any time.

6. Party B will provide Party A with a full set of promotional materials and related instructions for the above-mentioned cooperation "___________" project free of charge.

2. Cooperation period:

The cooperation period between Party A and Party B is _____ years, from ____ month ____, _____ year to _____ year On ____month____, both parties will have priority to renew the contract on the basis that there is no violation of the original cooperation agreement.

3. Cooperation operation regulations:

1. Cooperation sharing and payment method: The total turnover surplus of the cooperation project received by Party A and Party B shall be distributed according to this agreement. The percentage stated in the contract will be split and settled before the 5th of the following month of each business month. If both parties fail to complete the settlement within the specified time, both parties agree to add punitive liquidated damages to the defaulting party as compensation, and the other party has the right to immediately Termination of rights and obligations owed to the defaulting party.

2. Service execution requirements: Party A and Party B shall pay the cooperation commission fees to Party A and Party B in the form of monthly settlements after each sale of this cooperation project treatment course.

3. Non-competition regulations: During the execution of the contract, without Party B’s consent or Party B’s promotional activities, Party A’s sales (any channel) of Party B’s products shall not be less than the agreed price or 1.5 times higher than the agreed price. , if you violate this agreement and it is verified to be true, it will be deemed as a breach of contract.

4. Price and fee collection: During the execution of the contract, both parties agree that the project price can be adjusted according to market conditions after negotiation with other parties due to relevant operational needs, but the percentage of turnover earned by Party A and Party B is based on the split principle If there are any changes, they shall be stated in this contract in the form of amendments or supplementary clauses.

Both parties promise that if each party fails to implement the payment agreement as agreed after collecting the customer's money, the party in violation shall bear criminal liability for embezzlement and fraud.

5. Settlement regulations: The total operating income generated by all cooperative operations between the two parties will be temporarily collected by the collecting party stipulated in this contract. The full account of the current month shall be paid by Party A and Party B before the 5th of the following month. After accounting, each party will issue an invoice for the profit distribution to the other party. After both parties receive the payment invoice, they can offset the surplus distribution amount of the accounts receivable and payable, and the paying party will issue a check before the 10th of the month to pay the surplus distribution amount. .

6. Tax agreements: The taxes payable by Party A and Party B shall be borne by each party in accordance with national regulations.

7. Customer refund: When each cooperation project in this contract fails to complete the service after receiving payment, Party A and Party B shall deduct the service fees and product fees consumed by the customer, and calculate the turnover income from this cooperation project. , the refund will be split to the customer based on the percentage of profit allocated by the cooperation. If the customer cannot be present to terminate the contract, the contract will be deemed to have been fulfilled and no refund will be given. Related follow-up issues will be borne by the party collecting the payment.

Risk Warning

The cooperation method should be clearly agreed upon, especially if it involves different investment methods such as capital, technology, and labor services. At the same time, their respective equity shares should be clarified, otherwise it is easy to cause disputes over responsibility, profit and loss sharing, etc. during the actual operation of the project.

IV. Rights and obligations of Party A:

1. Responsible for providing Party A’s client base and terminal prospective customers.

2. During the cooperation period, Party A must increase advertising efforts, including local TV advertising, radio advertising, outdoor advertising, print advertising, etc. to promote the project in an all-round way.

3. Party A shall pay Party B the cooperation payment as required by the agreement and complete the operational goals during the agreement period.

4. Party A is obliged to assist Party B in marketing and product image promotion.

5. Party B’s rights and obligations:

1. Party B provides Party A’s sales staff with course training on the “___________” beauty project.

2. Responsible for providing formal ________ qualified personnel.

3. Provide relevant information and technical operations required for "___________" medical cosmetology.

4. Party B promises to fully protect Party A’s interests during its contact with Party A’s customers.

5. Party B is obliged to provide guidance and answers to the technical questions raised by Party A through telephone, fax, e-mail, etc.

6. Party B is obliged to assist Party A in marketing and product image promotion.

6. Legal liability for delayed payment:

1. Both parties shall not excuse, delay, refuse, or violate the payment agreement for any reason. If the above circumstances occur, both parties have the right to press the The contract proposes direct seizure, civil and criminal prosecution and other sanctions against the other party, and seeks compensation from the breaching party based on related liquidated damages such as damage to the interests of all parties and delayed payment.

2. Both parties agree that if the above situation occurs, the liquidated damages will be based on the profits that each party should share. For each day of delay in payment, the amount of profits multiplied by 1% of the punitive liquidated damages will be added. Until the payment is settled.

Risk Warning

Confidentiality and non-competition obligations should be agreed upon, especially for the technology and customer resources involved in the project, to avoid the possibility that one of the partners will make profits or engage in other activities outside the project. Activities that harm the rights and interests of the project.

7. Confidentiality Clause:

1. All parties shall fully abide by the relevant profit distribution and strictly maintain confidentiality. Except for the parties to this contract, they shall strictly not disclose all data of this contract to persons outside this contract. Information, when this contract is terminated, both parties shall return (or destroy) all relevant information and backups of the other party to the other party, and shall continue to have the obligation to keep it confidential until the confidentiality clause is terminated.

2. This confidentiality clause is valid for 1 year (calculated from the date of termination of this contract).

Risk Warning

Although the contract is detailed, there is no guarantee that the partner will not breach the contract. Therefore, the breach of contract clauses must be clearly agreed upon. Once one party breaches the contract, the other party can use this as a basis for recovery.

8. Breach of contract provisions:

1. Party A and Party B shall strictly abide by the provisions of this agreement. If one party’s breach of contract causes economic or other interest losses to the other party, breach of contract shall Each party shall compensate the other party for its losses and bear corresponding responsibilities.

2. If either party breaches the contract, it will compensate the other party for liquidated damages of RMB ______ million yuan (lowercase ______ yuan) as liquidated damages.

9. Dispute handling:

1. Any disputes arising from the execution of this agreement and related to this agreement shall be resolved in accordance with the principle of friendly negotiation.

2. If both parties cannot reach an agreement through negotiation, the matter shall be submitted to the ______ Arbitration Committee for arbitration.

3. During the dispute resolution process, except for the part under negotiation or arbitration, other parts of the agreement shall continue to be implemented.

10. Others:

1. For matters not covered, a supplementary agreement will be signed separately after negotiation between the parties. The supplementary agreement will have the same legal effect as this agreement.

2. This agreement is made in _____ copies. Party A and Party B each hold _____ copies. It will take effect after being signed and sealed by the legal representative or the authorized signing representative, and it will also be legally binding.

Party A:

Signature of legal representative:

_______month____day

Party B:

Signature of the legal representative:

Project Agreement 2 on ____ month ____ of _____ year

Party A: Huizhou Sanyou Technology Co., Ltd.

Party B: ID number:

Party C: ID number:

Based on the principles of fairness and mutual benefit, Party A, Party B and Party C have reached the following agreement:

1. Party A, Party B and Party C voluntarily cooperate to operate a cosmetics brand operation project. Party A invests in this project in the form of team resources, company qualifications, owned brands, operation planning, office space, etc. Party B invests RMB 100 Ten thousand yuan (￥100,000) was invested in this project, and Party C invested one hundred thousand yuan (￥100,000) in this project.

2. The cooperation period of this project is tentatively set for 3 years, starting from the month and day of 20xx to the month and day of 20xx. If it needs to be extended, the three parties will renew the agreement one month before the expiration of the agreement. This agreement will officially come into effect after Party B and Party C receive full funds.

3. Party A is fully responsible for all matters including overall project planning, and assumes corresponding responsibilities for disputes arising from product quality, brand infringement, after-sales service, etc. Party B and Party C are investors and do not participate in the daily operation and management of the project and assume no other commercial risk responsibilities.

4. The fixed assets, sales surplus, claims and debts generated by this project will be distributed in the proportion of Party A 40%, Party B 30%, and Party C 30%. If subsequent adjustments are needed due to operation and management, the three parties will separately negotiate and sign an agreement.

5. The cooperation between the three parties is limited to this cosmetics brand project, and the brand ownership belongs to Party A.

6. Party A is responsible for managing funds and providing monthly reports on project operation and fund usage for supervision by Party B and Party C by email.

7. Party B and Party C have the right to make suggestions on project operation. The final decision on project operation is determined by Party A, and Party B and Party C shall not have any objection.

8. Party B and Party C may propose to withdraw from the cooperation after one year of project operation, and will withdraw after the three parties have jointly liquidated fixed assets, sales surplus, claims and debts and signed an agreement.

9. Party B and Party C automatically become the cosmetics brand distributors of this project. They will collect goods in cash according to the highest dealer level set by Party A, and comply with the market retail price regulations set by Party A. Party B and Party C will enjoy A total of ***100 pieces of free samples for all items in this project.

10. This agreement is made in triplicate, with Party A, Party B and Party C each holding one copy, which has the same legal effect.

11. Other matters not covered shall be resolved through consultation among the three parties.

12. Attachments.

Party A: (Signature/Seal) Party B (Signature/Seal) Party C (Signature/Seal)

Agreement signing date: Project Agreement Part 3

Party A (original company shareholder): __________

ID number: __________

Party B (new investor): __________

ID number: __________

The _______________________ Company (hereinafter referred to as the "Company") is a company legally registered and validly existing on _______, month _______, _______. Party B is now interested in investing in the company and taking a shareholding. business.

Now, Party A and Party B have reached the following agreement after full consultation on the matter of investing in the company, in order to mutually abide by it.

1. Party A and Party B agree to invest in the company at the time of signing this agreement, agree on the company's various operating activities and continued value at this time, and invest in the company.

2. Party B invests 5 million yuan in the company.

3. After Party B invests, both parties agree to make the following adjustments to the company’s share structure: __________

Party A retains 45% of the company’s shares as the original shareholder;

Party B Obtain 35% of the company's shares;

The company's R&D and management team received 20% of the company's shares.

4. The relevant procedures such as changes to the company’s articles of association shall be handled uniformly after Party B completes the investment.

5. After Party B completes its capital contribution, it will enjoy corresponding rights and obligations and perform shareholder duties in accordance with the Company Law, Civil Code, Articles of Association and other laws and regulations.

6. Party B’s investment funds can be received in installments according to stages. The first installment of ____________ ten thousand yuan will be entered into the company’s account before ______ days of this month, and the second installment of investment funds will be ____________ ten thousand yuan. RMB will be entered into the company account before ______month______day______year.

7. After Party B completes the investment, all legal procedures will be completed immediately. If Party B cannot complete the investment within the period of this agreement, it will be deemed as a breach of contract. Party A has the right to terminate the cooperation and Party B's shares will be reduced accordingly according to the actual completed investment amount.

8. If Party B completes the capital contribution within the prescribed time limit, Party A shall not violate this agreement and must cooperate with the corresponding procedures for changing the articles of association and recognize Party B's legal shareholder rights.

9. Other breach of contract situations shall be resolved through friendly negotiation between Party A and Party B.

10. This agreement is made in four copies. Party A and Party B each hold one copy. The remaining two copies shall be submitted to the industrial and commercial administration for formalities. The signatures of both parties will take effect immediately.

11. This agreement is the basic content agreed between Party A and Party B regarding this investment in the company. The specific matters involved and the unexplained matters can be negotiated by the parties without violating the provisions of this agreement. A supplementary agreement is entered into under this Agreement, which shall have the same legal effect as this Agreement.

Party A: __________

Party B: __________

Authorized representative: __________

Authorized representative: __________

Signing date: __________

Signing date: __________ Project Agreement Part 4

Contract number: 119242

According to legal provisions, the contractor shall comply with legal provisions The licenses, approvals or filings handled by it include but are not limited to construction land planning licenses, construction project planning licenses, construction project construction licenses, temporary water use for construction, temporary electricity use, interruption of road traffic, temporary occupation of land, etc. Licenses and Approvals. The contractor shall assist the contractor in obtaining relevant construction certificates and approval documents as stipulated by law.

If the contractor fails to complete the aforementioned permission, approval or filing in a timely manner, the contractor shall bear the resulting increased costs and/or delayed construction period, and pay the contractor a reasonable profit. In accordance with the "Contract Law of the People's Republic of China", the "Construction Law of the People's Republic of China" and other relevant laws and administrative regulations, in order to further clarify the responsibilities of internal contracting operations, upon agreement between Party A and Party B, and in conjunction with the project For specific circumstances, the following agreement has been reached on Party B's various technical and economic indicators, contracted operation responsibilities and other matters:

Article 1. Project Overview

1. Construction Unit: Project Name: Project Location : Building area: Structural form: Contracting scope: Contracting method: Risk warning: Provisions on the actual completion date

When a dispute arises due to the confirmation of the actual completion date, the specific situation can be referred to the relevant provisions:

p>

If the project passes the completion acceptance, the date when the contractor submits the completion acceptance application report will be the actual completion date, and it will be stated in the project acceptance certificate; due to the contractor's reasons, the supervisor has not received the completion acceptance report submitted by the contractor. If the completion acceptance is completed within 42 days of the completion acceptance application report, or the project acceptance certificate is not issued after the completion acceptance, the date of submission of the completion acceptance application report shall be the actual completion date; if the project is used without authorization by the contractor without completion acceptance, the project shall be transferred The date of taking possession of the project shall be the date of actual completion. Project duration:

(1) The planned start date is _________year____month____,

(2) The planned completion date is _________year____month ____ days, total ***____ calendar days.

2. Quality level:

3. Contract price: Tentative total price: _______________ yuan. The building area shall be subject to the final area measured by the Housing Authority.

Article 2. Standards and regulations for the selection of contract documents

1. Applicable standards:

2. Applicable regulations:

Article Article 3. Responsibilities of Party A

1. Assist Party B in the construction and ensure that the project meets the construction conditions when delivered to Party B;

3. Responsible for project quality inspection and supervision; do a good job in analyzing Acceptance visas for some projects, and urge construction technicians to collect, organize and archive engineering technical data;

4. During the contracted construction period, Party B due to poor construction management or serious mistakes caused In the event of significant operating losses and the apparent inability to complete the contracting quota, Party A has the right to terminate this contract, investigate and deal with the responsible persons depending on the specific circumstances, and require Party B to withdraw unconditionally until legal liability is investigated;

5. In Party B’s case When encountering difficulties, they are obliged to coordinate with relevant departments to help solve practical problems so that Party B can smoothly carry out construction and production;

6. Water and electricity installation shall be designated by Party A’s construction company as a subcontractor;

7. When the project is completed, organize personnel to check and accept it in time;

8. Pay the project payment on time, and do not default on the project payment without reason.

Article 4. Responsibilities of Party B

1. The corresponding terms stipulated in this contract and the general contracting contract must be strictly performed;

2. The construction contract must be carried out in accordance with Complete the construction tasks according to the terms of the agreement, and obey Party A’s unified management, unified dispatch, and unified command;

3. Responsible for labor organization arrangements, reasonable combination, and improved work efficiency;

4. Responsible for daily work To implement safety precautions, organize construction in strict accordance with safety operating procedures, cooperate with full-time safety officers, and accept the management of Party A and the superior safety management department to prevent accidents. All safety responsibilities caused by Party B shall be borne by Party B.

5. Ensure the quality of the project, in accordance with the requirements of the specifications, and ensure that the quality of the project meets the requirements of the contract terms signed by Party A and the construction company. In the event of quality accidents and delays in the construction period, Party B will be responsible for the penalties of the construction unit and the company.

6. Adhere to civilized construction and keep the construction site civilized and tidy.

7. Do a good job in the return visit and maintenance work of the project. Due to Party B’s quality reasons, Party B must complete the maintenance work within the specified time. If Party B delays the maintenance time, Party A has the right to make other arrangements and the cost will be borne by Party B. .

Article 5. Payment method

1. The budget for this project is: ____________________; the method of deducting the advance payment for the project is: ____________________.

2. The project payment will be paid in _________, specifically:

(1) There is no advance payment for this project;

(2) On a monthly basis After completing the project quantity statistical report, and after review and confirmation by the supervisor and Party A, _____ of the qualified completed project payment will be paid;

(3) _____ of the total project payment will be used as a quality deposit. If there are no quality problems In case of other breach of contract, it will be paid to Party B after the completion of the project. On the contrary, if there are quality problems or other breach of contract, Party A has the right to directly withhold Party B's warranty deposit. If the loss caused to Party A exceeds the amount of the warranty deposit, Party B shall still compensate for the excess.

Article 6. Safety Management

1. The safety management personnel of the engineering project shall be appointed by Party A based on the nomination of Party B. Party B must follow Party A’s internal regulations when organizing the construction process. Establish and improve the project safety production guarantee system, establish and implement a safety production responsibility system, ensure the investment in necessary safety facilities, purchase necessary labor protection supplies, safety equipment and supporting facilities, eliminate accident hazards, and fully meet the needs of safety production; 2 Special operations personnel, including mechanics and electricians, must hold certificates to work and strictly implement relevant safety technical operating procedures to ensure safe construction. The construction machinery, tools and electrical equipment used at the construction site are in good condition and can operate safely;

3. In addition to safety publicity placards at the construction site, safety signs, warning signs, etc. must be hung at dangerous locations to ensure The personal and property safety of construction workers, passers-by, and surrounding residents;

4. Party B shall not violate operating regulations for construction, illegal operations, and barbaric construction are strictly prohibited. If a safety accident occurs, Party B shall be responsible for any legal liability and all expenses incurred. If the reputation of Party A is affected, Party A shall be compensated for its losses. Risk reminder: Responsibility for project quality that does not meet the standards

If the project quality does not meet the standards agreed in the contract due to the employer's fault, the employer shall bear the resulting increased costs and/or delayed construction period, and Pay the contractor a reasonable profit.

If the quality of the project fails to meet the standards agreed in the contract due to the contractor's fault, the employer has the right to require the contractor to rework until the quality of the project reaches the standards agreed in the contract, and the contractor shall bear the resulting increased costs and (or) delayed construction period.

Article 7. Quality Warranty Risk Warning: Commencement of Warranty Liability

The project warranty period shall be calculated from the date when the project is completed and accepted. The specific warranty period of the sub-projects shall be determined by the parties to the contract. It shall be agreed in the special contract terms, but shall not be less than the legal minimum warranty period.

During the project warranty period, the contractor shall bear warranty responsibilities in accordance with relevant legal provisions and contract agreements.

If the contractor uses the project without authorization before completion acceptance, the warranty period shall be calculated from the date of transfer of possession.

1. During the quality warranty period, Party B shall bear the responsibility for the quality warranty of this project in accordance with the relevant laws, regulations and rules. If Party A is entrusted to handle it, the required expenses shall be borne by Party B;

2. Party B promises to assume warranty responsibilities in accordance with the quality warranty period agreed in the "Construction Project Construction Contract" signed by Party A and the construction unit. The quality warranty period is calculated from the date when the project is completed and accepted and delivered to the construction unit;

3. Quality warranty responsibility, for items that are part of the warranty, Party B shall within ____ days from the date of receipt of the warranty notice Organize warranty. If Party B fails to organize the warranty within the agreed period, Party A can assign others to perform repairs, and the cost will be deducted from the quality deposit;

4. In the event of an emergency repair accident, Party B shall arrive immediately after receiving the accident notification Emergency repairs at the accident site;

5. For quality problems involving structural safety, they should be reported immediately to the local construction administrative department in accordance with the "Quality Warranty Measures for Housing Construction Projects" and safety precautions should be taken; The design unit or a design unit with corresponding qualification level proposes a warranty plan, and Party B implements the warranty;

6. After the quality warranty is completed, the construction unit and Party A organize acceptance.

7. The warranty costs shall be borne by the party responsible for the quality defects. Party B shall not charge any fees for quality problems caused by Party B’s construction.

Article 8. Project Subcontracting and Subcontracting Party B shall not subcontract or partially subcontract any project or labor service involved in this contract to others.

Article 9, Termination of Contract

1. Party A has the right to terminate the contract if Party B has the following circumstances:

(1) Failure to comply with the design specification requirements During the construction, the supervisor issued rectification notices for _______ times;

(2) The construction was delayed for ten days without entering the site, or the construction period was delayed by _____ for the same period as the construction progress plan;

(3) A major work-related injury accident occurs, or the failure to deal with the work-related accident in a timely manner affects the progress of the project or the victim claims rights against Party A;

(4) The arrears of materials and labor costs are not dealt with in a timely manner , causing relevant personnel to claim rights against Party A.

2. If Party A fails to allocate the project funds as required by the contract and exceeds the amount of project funds that should be allocated, Party B has the right to terminate the contract.

3. Party B shall clear the site within ____ days after Party A terminates the contract. For each day overdue, Party B will voluntarily pay _______ of the total project price as liquidated damages to Party A. Risk reminder: Clarify liability for breach of contract

When signing a contract, both parties must think of possible breaches of the contract and stipulate corresponding punishment methods in the contract. By clarifying the responsibilities that need to be borne in the event of breach of contract, Urge all parties to truly perform their obligations and provide evidence-based evidence in the event of a breach of contract.

Article 10. Liability for breach of contract. Party A and Party B shall perform this agreement in accordance with the principle of good faith. If either party violates the above terms and causes the failure of performance of this contract or defective performance, it shall bear the corresponding liability for breach of contract. .

Article 11. Methods to resolve disputes

1. If a dispute arises during the performance of this contract, the parties shall first resolve it through friendly negotiation. If negotiation is not possible, it can also be resolved through reconciliation or mediation. When the dispute cannot be resolved through non-litigation, both parties can file a lawsuit with the people's court at the place where the contract was signed, the place where the contract was performed, or the place where the defendant is domiciled.

2. If Party B files an external lawsuit in the name of Party A due to the needs of this project, Party A shall provide assistance. The relevant attorney fees, litigation fees, preservation fees, etc. shall be borne by Party B.

Article 12. This agreement is made in ______ copies, with each party holding ______ copies, and shall take effect from the date of signature.

Article 13. Matters not covered in this agreement shall be resolved through negotiation between the two parties.

Party A (signature and seal): Legal representative: Authorized representative (signature): _________year____month____ Party B (signature and seal): Legal representative: Authorized representative (signature) :_______year____month____day