Advertising installation contract template [5]

Article 1 Model advertising installation contract

Party A: (hereinafter referred to as Party A) Party B: Advertising (hereinafter referred to as Party B) In order to clarify their respective rights and obligations, through friendly negotiation, Party A and Party B hereby undertake the production and installation of billboards (hereinafter referred to as billboards) for Party B in accordance with the provisions of People's Republic of China (PRC) Contract Law, People's Republic of China (PRC) Advertising Law, Regulations on Construction and Installation Contracts and other laws and regulations.

One: billboard production

1, billboard specifications:

2, material:

3. Requirements:

Two: billboard installation

Installation location:

3. Project cost and payment method

1. Billboard production fee (i.e. total contract price): * * * RMB only, in words.

2. Payment method:

A. When signing the contract, Party A shall pay 30% of the project cost in advance.

B. After the fabrication and installation are completed, Party A shall pay off all the project funds after passing the acceptance.

Four: the construction cycle

1, from the date when Party A prepays the project payment after the signing of this contract. In case of force majeure factors (such as rain, snow, gale above level 4), the construction period will be postponed.

2. If Party B's work can't be completed on time due to Party A's repeated revisions, the extension time can be determined by both parties through consultation.

Verb (abbreviation for verb) Rights and obligations of both parties.

Party A:

1, go through the necessary examination and approval procedures and related expenses for billboard installation.

2. Have the right to put forward suggestions and amendments to Party B's design, so that the works designed by Party B are more in line with the cultural connotation of Party A's unit.

3. Provide Party B with the location of the billboard, and ensure that there is no pipeline in this location, so it can be constructed.

4. Party B has the obligation to provide relevant company information or other relevant information for Party B's design reference.

5. The trees, flowers and plants responsible for the construction site can be moved.

6, according to the provisions of this contract settlement billboard production and installation costs.

Party B:

1. After Party A notifies that the site construction can be carried out, it shall complete the construction and installation within the specified time according to the installation location provided by Party A. ..

2, in strict accordance with the construction plan drawings confirmed by Party A for production and installation. If the site conditions are inconsistent with the construction drawing scheme, it shall be reported in time.

1 page (page ***2 of this contract, stamped with the riding seal)

Please consult Party A for modification and confirmation.

3. Party B enjoys the copyright of the design works.

Six: About acceptance

1. Within one week after Party B completes all production and installation, Party A must organize formal acceptance; If Party A fails to organize the acceptance within one week after the completion, it shall be deemed that the quality of the project accepted by Party B is qualified.

2. The project quality acceptance is based on the national steel structure building standards, and the advertising structure is made and installed firmly, and the wind resistance level reaches 7.

Seven. Liability for breach of contract:

1. If Party A fails to make payment according to the time stipulated in Article 3 of this contract, Party A shall pay 0.5% of the total contract price as liquidated damages to Party B for each day overdue, and extend the contract period.

2. If Party B fails to complete the production and installation of billboards on time as stipulated in Article 4 of this contract without justifiable reasons, Party B shall pay 0.5% of the total contract price to Party A as liquidated damages for each overdue day.

3. Party B shall ensure that the project quality, structural firmness, wind resistance and other indicators meet the national standards. If it is unqualified, Party B shall bear the rework and corresponding losses.

4. If it is due to Party A's reasons, Party A shall be responsible for stopping work, construction and demolition. Party B has the right to require Party A to pay part or all of the production costs according to the actual construction conditions.

Eight. Responsibility arising from advertising:

1. During the production and setting of this advertisement, if the personal or property damage of a third party is caused by Party B, Party A has nothing to do with it.

2. Party A shall bear all responsibilities for disputes arising from trademarks, portraits, advertising words and other advertising contents provided by Party A. ..

Nine, warranty period:

1. From the date of acceptance, the quality of engineering steel produced by Party B shall be guaranteed for half a year. Party B is not responsible for the warranty for man-made damage.

2. After the warranty period expires, both parties shall re-sign a maintenance agreement for maintenance.

X any dispute arising from this contract shall be settled through friendly negotiation. If negotiation fails, it shall be arbitrated by Changting County Arbitration Commission.

XI。 This contract is made in duplicate, one for each party, with the same legal effect.

12. This contract has legal effect once it is signed.

Party A: Party B:

(Seal) (Seal)

Legal person/authorized representative (signature): Legal person/authorized representative (signature):

Tel: Tel:

Date, year and month

Article 2 Model advertising installation contract

In accordance with the Advertising Law of People's Republic of China (PRC), Model Contract Law of People's Republic of China (PRC) and relevant national laws and regulations, Party A and Party B have reached an agreement on entrusting Party B with the production and installation on the basis of equality, voluntariness, equal compensation, fairness and good faith, and hereby sign this model credit contract. First, the way and scope of contracting

This project adopts contract, material contract, contract production, contract installation, contract quality, contract duration, contract safety and contract risk, and Party B adopts fixed general contract. In the process of construction, no matter how the market price changes, both parties shall settle the contract according to the price determined in this model contract. Party B must complete the overall production and installation of the items listed in Article 3 with good quality and quantity according to the design scheme determined by Party A. ..

Second, the total cost and payment method

1. The total cost of the model contract (including tax) is RMB, in words: RMB only. After entering the model contract period, Party B shall be responsible for all expenses incurred in the production and installation process listed in this model contract.

2. On the first working day after both parties sign the model contract and confirm the detailed draft, Party A shall pay Party B 30% of the total amount, namely RMB, as the project start-up fund. 65%, i.e. RMB Yuan, shall be paid within 26 working days after all the work is completed and Party A's acceptance reaches the acceptance standard stipulated in the model contract, and the remaining 5% shall be paid as quality deposit, which shall be paid within 12 working days after the expiration of the quality guarantee period and acceptance by Party A.. ..

3. Party A will pay the above payment in the form of, and Party B must provide the corresponding invoice at the same time.

Third, production materials and demand, cost budget

Remarks: Party A will increase or decrease the engineering quantity two working days in advance according to the actual situation, and Party B will work according to the increase or decrease items in the Power of Attorney for Project Increase or Decrease signed and confirmed by Party A.. The total amount of the demonstration contract is adjusted according to the actual engineering quantity, and the unit price of the demonstration contract remains unchanged.

Four, production and installation time:

See Article 3 Completion Time for details.

Verb (abbreviation of verb) acceptance process

1. Manufacturing standard: Party B must manufacture and install according to the manufacturing process and materials provided to Party A. If the manufacturing process and materials need to be changed, Party A must obtain the consent in advance, otherwise Party A has the right not to perform any terms of this model contract.

2. Manufacturing and installation: Party A shall accept the raw materials according to the process standards provided by Party B, and Party B shall install them safely and reliably, and Party A shall sign and accept them on site.

The responsibility of both sides of intransitive verbs

1. Party A is responsible for determining relevant project materials (screen design renderings) within the agreed time, and is responsible for the determined materials;

2. Party A shall pay the advertising production and installation fees to Party B on time according to the provisions of this model contract;

3. Party B must complete all the installation and production projects with good quality and quantity within the specified time according to the model contract. If Party B fails to complete all production and installation projects according to the requirements of the model contract, 65,438+0% of the total project cost will be deducted as penalty for each overtime day (if it is less than 24 hours). If the materials or processes do not meet Party A's requirements, Party A has the right to terminate the cooperation with Party B, and Party B shall refund the payment made by Party A and compensate Party A for its losses.

4. For details about the warranty period, please refer to point 3. If there is any damage during the warranty period, Party B must guarantee to arrive at the site for maintenance within 48 hours, and deduct 5% of the quality deposit (5% of the total amount) from Party B for each day exceeding the warranty period. Party A also has the right to repair itself as appropriate, and the required funds can be directly deducted from the quality guarantee fund;

5. During the performance of the model contract, Party B shall take full responsibility for all safety accidents. In the event of a direct safety accident, Party A will not bear any joint liability.

Seven. responsibility for breach of contract

1. Party A shall pay the expenses to Party B according to the amount and time specified in this model contract. If Party A fails to pay the fees within the time limit, Party B has the right to recover the fees owed.

2. Party B shall strictly perform all the terms of the model contract, and agree to bear corresponding liabilities for breach of contract under the following circumstances: Party B must complete all the manufacturing and installation work within the specified time, which shall not exceed 5 days (including 5 days), and Party A may claim compensation from Party B according to point 3 of Article 6. After 5 days, Party A has the right to terminate the model contract and claim all losses of Party A from Party B in double indemnity.

3. After the model contract comes into effect, if Party A requests to terminate or dissolve the model contract without justifiable reasons, it shall compensate Party B for its losses. If Party B terminates or cancels the model contract without authorization, it shall pay the amount paid by Party A in double indemnity and compensate Party A for its losses.

4. Party B shall not disseminate or transfer the materials submitted by Party A and the completed entrusted projects specified in this model contract to a third party, otherwise Party A has the right to claim compensation from Party B. ..

Eight. Method of dispute settlement

All disputes arising from the execution of this model contract or related to this model contract shall be settled by both parties through friendly negotiation. If negotiation fails, either party may bring a lawsuit to the people's court with jurisdiction.

Nine. others

1. Either party shall propose in writing to terminate the model contract, and it can only be terminated with the consent of both parties.

2. If the demonstration contract cannot be performed due to force majeure, both parties shall settle it through negotiation in time.

3. This model contract shall come into effect after being signed by both parties, and will be automatically terminated after both parties have fulfilled it.

4. For matters not covered in this model contract, both parties can sign a supplementary agreement as an annex, which has the same effect as this model contract.

5. This contract is made in duplicate, each party holds one copy, and each copy has the same legal effect.

6. Other agreements:

Party A: Party B:

Address: Address:

Legal representative (or authorized contractor) Legal representative (or authorized contractor)

Article 3 Model advertising installation contract

Advertiser: (hereinafter referred to as "Party A") Advertiser: (hereinafter referred to as "Party B")

Place of signing the agreement:

Party B has the right to publish advertisements on some bus lines in xxx, and Party A requests to publish advertisements on the media owned by Party B. Through friendly negotiation, both parties have reached the following agreement:

First of all, show the product brand:

Second, the form of advertising: bus body advertising (on both sides of the body)

Third, the number of media: vehicles.

Fourth, the advertising period

1. Both parties confirm that the advertising release period is.

2. Both parties agree that the expected release date of the advertisement is from MM DD YY to MM DD YY.

3. Both parties agree that the release date of Party A's car body advertisement is the date when the actual bicycle advertising car body is on the road.

Five, advertising fees and line details are attached to the annex to the agreement.

6. Payment method: 50% of the total amount, namely RMB, shall be paid within three days after signing the agreement. Pay off the balance within seven days after all the advertisements are on the road, that is, RMB only.

Seven. Rights and responsibilities related to payment

1. During the advertising period, if Party A needs to change the pictures, the actual cost of making and pasting the pictures will be paid to Party B separately.

2. After Party B confirms that Party A's payment has arrived, it can provide or send invoices.

3. If Party A delays payment, Party A shall pay Party B a penalty of 0.2 ‰ of the total amount of this agreement for each day overdue, and the penalty shall be paid together with the penalty within one week from the day after the agreed payment. If Party A delays payment or fails to pay the specified amount,

If the overtime is one week, Party B has the right to cancel Party A's advertising screen and unilaterally terminate the agreement. The money previously paid by Party A will not be refunded, and Party B will be paid a penalty equivalent to the balance of the agreement.

4. Payment method of Party A:

4. 1 If the payment is made in cash (RMB), Party A must first receive the receipt sealed by Party B, otherwise it will be deemed invalid and the consequences will be borne by itself.

4.2 If the payment is made by transfer cheque (RMB), Party A shall correctly fill in the cheque and make it payable (see the agreement chapter). If Party A fails to fill in the cheque, or if the cheque is incorrectly filled in, if there is any problem with the cheque received, Party A shall bear the consequences.

Eight, advertising design

1. If Party A needs Party B to design advertisements for its products, Party A shall submit the necessary design materials to Party B within fifteen days before the expected release date of the agreement, and confirm the samples and colors within three days after Party B notifies Party B to complete the samples.

2. If Party A independently designs advertisements, Party A shall submit samples that meet the requirements of laws and regulations and the body advertisement examination and approval authority to Party B ten days before the expected release date.

3. If the advertisement cannot be postponed as scheduled due to Party A's violation of the above-mentioned agreed time, the loss expenses shall be borne by Party A. If Party A still fails to perform the contract after reasonable notice from Party B, Party B has the right to unilaterally terminate the agreement.

4. Party B enjoys the copyright of design samples. Without Party B's permission, Party A shall not use it anywhere other than the advertisements agreed in this agreement. In case of violation, Party B has the right to claim compensation.

5. If Party A and Party B use portraits and other elements in advertising design, they must ensure the legality of their use, otherwise the legal disputes will be at their own risk.

Nine, advertising production, release and post maintenance

1. Party B is responsible for the approval, production and release of advertisements, as well as the cleaning and maintenance of the advertising vehicles themselves.

2. If the advertisement actually stops due to a bus accident during the release period, Party B shall report to Party A within five working days and be responsible for the repair costs. The bus stop time due to maintenance shall be subject to the written certification materials of the company to which the team belongs, and shall be postponed after the expiration of normal release after being signed and confirmed by both parties.

3. When the advertisement of the operating vehicle is damaged, after confirmation by both parties, Party B shall repair it free of charge within seven working days. After the normal release period expires, the advertisement release time will be postponed.

4. Party B shall make and publish advertisements in strict accordance with the design draft confirmed by both parties. In case of violation, Party B shall unconditionally re-formulate. Therefore, Party A will no longer bear its production expenses; The resulting suspension time will be extended beyond the release date of the agreement.

X. Quality acceptance criteria

After the car body is made, Party B shall deliver the customer acceptance form to Party A in time, and Party A shall, within one day after receiving the acceptance form provided by Party B and the photos of the previous issue, check and accept the car body advertisements signed in the agreement according to the general standards for making and pasting car body advertisements in Harbin, and sign for confirmation. (If Party A fails to accept the goods within the time limit or fails to fully accept them, the acceptance shall be deemed as complete).

Article 4 Model advertising installation contract

Party A (publisher): _ _ _ Advertising Co., Ltd. Party B (advertiser): _ _ _ Group.

Agreement number:

Signing place:

Signature time: _ _ _ _ _ _ _ _

According to the Advertising Law and the Regulations on Advertising Management, Party A and Party B sign this agreement on matters related to content advertising, which shall be abided by jointly:

First, the form of advertising: street signs

2. Advertising location: urban road number

Three. Advertising specification: 6_ 10m

Four. Advertising duration: from _ _ _ _ to _ _ _ _ _, * * years. The actual release time is subject to the release time confirmed in the acceptance report.

Verb (abbreviation for verb) Advertising price:

1. advertising fee: including publishing fee, land occupation fee, maintenance fee, insurance fee and basic frame production fee. Unit price 10000 yuan/block, 19 block. The total amount for the whole year is _ _ ten thousand yuan.

2. Payment of advertising fee: Phase I: Party B shall pay the advertising fee to Party A within 15 days after the signing of this agreement, totaling RMB.

The responsibilities of both sides of intransitive verbs:

1. Party A is responsible for the approval procedures of outdoor advertisements, the approval and acceptance of advertising samples, and the warranty maintenance during the release period.

2. Party A is responsible for providing advertising samples, and Party A is responsible for submitting advertising samples to relevant departments for approval. If the approval fails, it will be returned to Party B for modification. Once confirmed, the draft will serve as an effective basis for production and acceptance, and will be kept together with this agreement as an annex to this agreement. The expenses arising from the difference between Party B's requirements and the original samples shall be borne by Party B, and Party A shall not delay the advertising time.

3. Party A shall complete the production within 30 days after receiving the first payment from Party B and confirming the advertising draft. Within 3 days after the completion of production, Party A, Party B and the producer * * * all passed the acceptance test, and Party B signed the acceptance report. If Party B fails to do the acceptance test in time after receiving the notice from Party A, Party A will consider Party B qualified for more than 3 days.

4. Party B shall pay on schedule. If Party B fails to make payment on schedule, Party A has the right to terminate this agreement and not reserve advertising space.

5. During the advertising period, if the advertising is terminated due to Party A's responsibility, Party A shall bear the responsibility; If the advertisement is terminated due to Party B's responsibility, Party B shall bear the responsibility; If the advertisement is terminated due to force majeure, both parties shall settle it through friendly negotiation.

Seven. Agreement renewal:

65,438+0 months before the expiration of this Agreement, both parties may renegotiate the extension of this Agreement. Under the same conditions, Party B enjoys priority. If Party B fails to go through the renewal formalities at the expiration of the agreement, Party B will no longer enjoy the priority and the advertising space will no longer be reserved.

Eight, any party violates the agreement, the two sides can not negotiate, can apply to the economic agreement arbitration organ for arbitration or to the people's court.

Nine. Supplementary terms:

1. This agreement is made in duplicate, with each party holding one copy.

2. The annex to this agreement is in duplicate, with each party holding one copy.

3. For matters not covered in this Agreement or the need to modify this Agreement, a supplementary agreement may be signed.

4. This agreement shall come into force as of the date of signature and seal.

Party A: _ _ Advertising Company Party B: _ _ Group

Representative: _ _ Representative: _ _

Bank: _ _ Bank Bank: _ _ Bank

Account number: _ _ _ _ _ Account number: _ _ _ _ _ _

Tel: _ _ _ _ _ Tel: _ _ _ _ _ _

Fax: _ _ _ _ _ _ Fax: _ _ _ _ _ _

Article 5 Model advertising installation contract

Party A: Party B:

According to the People's Republic of China (PRC) Agreement Law and relevant laws and regulations, Party B accepts the entrustment of Party A, and both parties reach a consensus on the entrusted design, sign this agreement and faithfully perform it:

I. Contents and requirements of the agreement:

Second, the design and production costs:

The total cost of design and manufacture is: RMB Yuan (in words: RMB Yuan only).

Three. Payment terms:

1. Party A shall pay% of the total cost of commissioned design and production when signing this agreement, that is, RMB _ _ _ _ _ _ _ (in words).

3. When Party B delivers the design printed matter to Party A, Party A shall pay the balance of the agreement to Party B, namely RMB Yuan only (in words:).

Four. Time and delivery method of designing and producing works:

1. Party B shall complete the design scheme within the time agreed by both parties. If Party B's work can't be completed on time due to Party A's repeated revisions, it can be postponed, and the extension time shall be determined by both parties through consultation.

Verb (abbreviation for verb) intellectual property agreement:

1. The copyright of the work designed by Party B belongs to Party B before Party A pays all the commissioned design and production expenses, and Party A has no rights to the work.

2. After Party A has settled all the expenses of the commissioned design and production, Party A has the ownership, use right and modification right of the works.

Rights and obligations of intransitive verbs;

Rights of Party A:

1. Party A has the right to put forward suggestions and ideas on Party B's design to make the works designed by Party B more in line with Party A's corporate culture.

2. Party A has the right to propose amendments to the works designed by Party B;

3. After paying all the design fees, Party A enjoys the ownership, use right and modification right of the design works;

Obligations of Party A:

1. Party A has the obligation to pay relevant expenses according to this agreement;

2. Party A has the obligation to provide Party B with relevant enterprise information or other relevant information;

Rights of Party B:

1. Party B has the right to request Party A to provide relevant enterprise information for Party B's design reference;

2. Party B has the right to require Party A to pay the corresponding amount according to this agreement;

3. Party B enjoys the copyright of the design works and has the right to ask Party A not to use the design works before paying off the money;

Obligations of Party B:

1. Party B shall design and produce works according to the requirements of Party A..

2. Party B shall deliver the design and production works on time according to the agreement.

Seven. Liability for breach of contract:

1. Party A terminates the agreement before the first draft of the design works is completed, and its prepaid expenses are not entitled to be refunded; If Party A terminates the agreement after the completion of the first draft of Party B's works, it shall pay all the design fees.

2. If Party B terminates the agreement in advance without justifiable reasons, all the fees collected shall be returned to Party A. ..

Eight. Entry into force of the agreement:

This agreement is made in duplicate, one for each party and signed by the other party, with the same legal effect. This agreement shall come into force as of the date of signature and seal.

Party A (seal): Party B (seal):

Signature of Party A's Representative: Signature of Party B's Representative:

Address: Address:

Tel: Tel:

Fax: Fax:

Open an account:

Account number:

Date: Year Month Day Date: Year Month Day