Model contract for retaining wall engineering?

Model tripartite agreement for engineering, for reference only.

Employer: (hereinafter referred to as Party A)

General contractor: (hereinafter referred to as Party B)

Subcontractor: (hereinafter referred to as Party C)

With the consent of Party A, Party B and Party C through negotiation, Party B subcontracts xx waterproof project to Party C, and in order to clarify the responsibilities and rights of the three parties, the following agreement is reached through negotiation.

I. Project name:.

Two. Project location:.

Three. Project content:.

4. Project cost: about xx million yuan, X yuan /m2, which shall be settled according to the waterproof exterior area of the waterproof engineering entity (according to the requirements of the specification, the single-layer area shall be calculated separately for the part where additional layers should be added, but the overlapping layers shall not be calculated repeatedly, only the single-layer area shall be calculated).

5. Contracting method: contracting labor, materials and unit price at one time (including all expenses such as materials, labor, machinery, management fees, inspection fees, taxes and risks).

6. Construction period: 20xx to 20xx years. The commencement date shall be subject to the notice of Party B. If the construction site does not meet the construction conditions and weather conditions, the construction period will be postponed.

7. Quality: It meets the requirements of current national standards.

Material requirements: The materials used shall provide relevant quality certificates, and be inspected as required and bear relevant expenses. Waterproofing and auxiliary materials must be produced with main materials, otherwise, in addition to replacing them with main materials, the construction party will bear 20% of the project cost as liquidated damages.

9. Material specification and manufacturer: the materials are 1.5 mm thick "Aositai" brand PVC waterproofing membrane and 1.5mm thick "Aositai" brand AST synthetic polymer waterproofing coating .. produced by Shandong Liaocheng Tianlong Construction Development Co., Ltd.

X. Payment method of project funds: (1) 40% of the contract price shall be paid after the materials enter the site; (2) Pay 40% of the contract price after the bottom plate construction is completed; (3) Pay the retaining wall to 95% of the contract price after acceptance and settlement; (4) Leave 5% as the project warranty fund, which will be paid within one year.

After being signed and approved by the supervision company and the general contractor, the construction unit will directly pay the project payment to Party C. ..

XI。 Rights and obligations of both parties

1. Party A and Party B have the right to supervise, inspect, guide and serve Party C's construction, coordinate internal relations, and have the right to punish violations.

2. Party C must strictly organize the construction, obey the management, and cooperate with various inspections to ensure the project quality.

3. In the process of construction, Party C shall put an end to heavy casualties. In case of safety accidents, all casualties or property losses shall be borne by Party C. ..

4. Party C shall protect Party A and Party B from any claim, compensation, lawsuit and other expenses and responsibilities caused by Party C. In case of the above, all responsibilities and expenses shall be borne by Party C. ..

5. This project is constructed by the team directly under Party C, and subcontracting or subcontracting is not allowed. If subcontracting is found, Party A has the right to terminate the contract, and Party A will not pay the expenses incurred by Party C. ..

6. All waterproof fees shall be deducted after the general contractor collects fees and taxes. The above expenses have nothing to do with Party C. ..

12. Completion acceptance: Before the completion of the project, Party C shall sort out all necessary materials and submit them to Party B according to Party B's requirements, and bear relevant responsibilities and losses in case of delay.

Thirteen. Liability for breach of contract:

1. Due to Party C's reasons, 500 yuan will be fined for every day that the project is delayed.

2. In case of quality problems, Party C shall bear all economic losses of Party A and Party B. ..

XIV. Project Warranty: Party C shall be responsible for the project warranty and pay the expenses.

15. Dispute: In case of dispute, it shall be settled through negotiation. If negotiation fails, both parties may bring a lawsuit to the court where Party A is located.

16. This agreement is made in triplicate, with each party holding one copy.

Seventeen. This agreement shall come into force after being signed and sealed. Matters not covered shall be discussed separately.

Party A: (Seal) Legal Representative

(or entrusted agent)

Party B: (Seal) Legal Representative

(or entrusted agent)

Party C: (Seal) Legal Representative

(or entrusted agent)

February xx 1 day