Factory building demolition contract

With the continuous development of the spirit of the rule of law, people are paying more and more attention to contracts, and there are more and more interest disputes about contracts. Signing a contract can more effectively restrain breach of contract. So how is a general contract drafted? The following is a factory demolition contract template (8 general articles) that I compiled for everyone. Welcome to read and collect it. Factory Building Demolition Contract Part 1

Party A:

Party B:

In accordance with the "Contract Law of the People's Republic of China" and other relevant laws and regulations, this agreement Based on the principles of equality, voluntariness, honesty and trustworthiness, after negotiation between Party A and Party B, the agreement on the contracting of the factory demolition project entrusted by Party A to Party B is as follows:

1. Project name

Bazhou City xx Industrial Co., Ltd. 550 hot rolling workshop demolition project

2. Project content

1. Demolish the workshop building to the ground level, and dismantle the concrete corbels of the material yard to the underground joint .

2. Dismantle the tracks, concrete driving beams, markings, etc. in the workshop and material yard.

3. The dismantled steel structure materials, color plates, doors and windows, etc. are transported to the designated location in Party A’s yard. The construction waste, concrete corbels, and concrete driving beams are removed and transported to the outside of Party A’s yard.

3. Contracting method

Party B is responsible for all related costs such as labor costs, machinery costs, transportation costs, tool costs, and material costs used in the project.

4. Project price

1. The price for dismantling the factory building is 18 yuan per square meter, and the settlement is based on the actual construction area.

2. After the concrete corbels and concrete driving beams are removed, they will belong to Party B, and Party A will no longer pay the cost of dismantling these parts.

5. Payment and Receipt Method

Appropriations will be made according to the progress of the project. After the completion of the project and acceptance by Party A, the entire project payment will be paid.

6. Project Period

Construction will start on November 21, 20xx and be completed before December 10, 20xx. The project period shall not exceed 20 days.

7. Safety Responsibilities

Before construction, Party B shall conduct safety education for its construction personnel. During the construction process, Party A has the right to inspect Party B’s unsafe conditions of property and unsafe behaviors of people. Inspect, supervise, and issue rectification instructions. If a safety accident occurs to Party B, or if the project causes damage to Party A or a third party, Party B shall bear full responsibility.

8. Project acceptance

Party B shall apply for project completion acceptance, and Party A shall accept it in time. If you do not apply for acceptance or do not accept timely, the relevant responsible party will bear the responsibility.

9. Liability for breach of contract

1. If a breach of contract occurs during the performance of this contract, the breaching party shall bear the corresponding breach of contract and compensate the other party for the economic losses caused

2. If the project is not completed within the project period, Party B shall pay liquidated damages of 10% of the total project price for each day of delay.

10. Other Agreements

1. If the completion of the project is delayed due to Party A’s reasons or natural disasters, the project deadline may be extended.

2. Unfinished matters and project changes must be implemented after mutual agreement and confirmation.

3. This contract will take effect after being signed by both parties.

Party A (official seal): _________

Party B (official seal): _________

Legal representative (signature): _________

Legal Representative (Signature): _________

___________month__________________

___________month________ Factory Building Demolition Contract Part 2

Party A:

Party B:

Due to the decoration contract required for Party A’s project, the construction part of the steel structure demolition project is now contracted to Party B. For the purpose of clarifying Responsibility, the following terms are hereby made for both parties to abide by.

1. Project content

Party B is responsible for dismantling and implementing the structures and equipment listed in the quotation list of part of the steel decoration contract in the current factory area, and will transport the parts according to the details of "Party A's retained list of steel". When arriving at the designated location, the property rights belong to Party A, and the rest, including all building materials and equipment, belong to Party B. The demolition scope involved in this project is the steel structure materials and indoor equipment, excluding any content outside the "part of the steel list retained by Party A" and the area designated by Party A. Party B is also responsible for the removal and transportation of construction waste materials, and the on-site cleanup to the ground. Party B must complete all the work contents in the quotation list of the decoration contract of the project and comply with the specification requirements.

2. Project price

2.1. Party B shall pay Party A for the project after negotiation between the two parties. The total price is RMB

yuan, and the settlement time is the date of signing the contract. This price has taken into account the value of all scrap materials, labor costs, freight, construction material fees, construction equipment fees and all clearing expenses due to Party B. Costs related to urban management, sanitation, landfills, spoil sites, etc. related to garbage transportation, as well as liability compensation to Party A and third parties due to safety accidents in this project.

2.2. Compensation costs: Party B. Commitment to complete the demolition project as required by the contract, without charging for the demolition fee and to compensate Party A for the cost of used materials (￥.00 yuan)

2.3. Payment method: After the contract is signed. Within days, Party B must pay the full compensation fee to Party A. After receiving the payment, Party A will issue a receipt to Party B for the electronic version of the decoration contract.

3. Things to note in the decoration contract: Don’t ignore the quality of the project.

After contacting the relevant departments, the demolisher should complete the removal and removal of various pipelines (such as water, electricity, gas, etc.) that require attention when signing decoration contracts that affect the safety of the demolition project. If any unknown cables or pipes are found in the electronic version of the construction and decoration contract, the construction should be stopped and necessary emergency measures should be taken, and the relevant functional departments should be reported in a timely manner. Construction can only be resumed after handling. In the factory area, Party B shall unconditionally obey Party A's inspection and strengthen on-site construction quality management. Party A has the right to change the construction team based on Party B's construction performance.

4. Construction Period

Party B must have enough manpower and relevant equipment to enter the construction site, and must complete all project contents before the date of the year.

5. Deposit

Party B must pay the deposit before entering the construction site.

Yuan decoration contract template is used as a commitment to the risks of this project. After the project is completed, both parties will inspect and accept the deposit and refund the deposit if the garbage is not cleaned up and causes additional losses to Party A.

6. Production safety

Party B is responsible for all the details that need to be paid attention to when signing the decoration contract. How to write a repair contract at the construction site, and all safety accidents will occur. All responsibilities shall be borne by Party B and Party A shall not be held responsible.

7: Breach of Contract Clause

If Party B violates the terms of this contract during the construction process of the decoration contract and cannot make corrections after being notified three times and causes serious losses to Party A, it shall be deemed In case of material breach of contract, the contract will be automatically terminated and Party A will no longer refund the deposit. If Party B causes a safety accident during construction, the construction shall be stopped immediately. If it cannot be properly handled in time, the contract will be automatically terminated and Party B will be responsible for all responsibilities, and Party A will no longer refund the deposit.

8. This contract is made in four copies, with each party holding two copies. It will take effect from the date of signing. It will be invalidated after the project is completed and the payment is settled, and the matter will not be resolved through negotiation.

Party A (official seal): _________ Party B (official seal): _________

Legal representative (signature): _________ Legal representative (signature): _________

_________year____month____day

_________year____month____day Factory Building Demolition Contract Part 3

Party A:

Party B:

After review of qualifications, Party A plans to have Party B carry out the house demolition project in the designated plot of land. In order to clarify the responsibilities and obligations of both parties, a house demolition contract is signed as follows:

1 . Demolition scope: Details that need to be paid attention to when signing the decoration contract for 30 bungalows on the south side of the courtyard

2. Demolition period: The demolition period is 10 days. The specific demolition date will be determined by telephone and written notification. If the demolition period exceeds the specified time, a fine of 1,000 yuan will be calculated for each day of delay.

3. Demolition standards: The demolished buildings should be cleared to the foundation, the ground inside the house (cement floor) should be cleared, and all demolition garbage should be removed. Finally, the construction site was leveled, garbage was emptied, and restored to its original appearance.

IV. In the decoration contract of this house demolition project, Party B must pay attention to the decoration contract and do not ignore the following:

1. Obey Party A’s decoration contract quotation list management and actively cooperate with Party A The project shall not be transferred or subcontracted in any form.

2. The designated main person in charge and the person in charge of the site shall not be changed at will. If changes are really necessary, Party A’s consent must be obtained.

3. How to write a strict decoration contract? Comply with the safety management regulations for house demolition projects formulated by the relevant superior departments. Safety responsibilities are in place and civilized construction. All safety responsibilities during construction are the responsibility of Party B and have nothing to do with Party A. .

4. Take safety precautions when demolishing a house, mark safety warning signs, and ensure the safety of buildings and people entering and exiting the surrounding demolished house. If an accident occurs, Party B shall bear all responsibilities.

5. During the construction process, construction workers are not allowed to take away things outside the scope of demolition. If any behavior is taken away from the decoration contract, Party B will be held accountable.

6. Party B must dismantle the dismantled parts in the factory at one time without leaving any future troubles.

5. Cost settlement: The old items removed from the house (doors, windows, sandalwood strips, steel beams, etc.) belong to Party B, and Party B’s demolition project costs will be calculated from the old items. According to the appraised value of the demolished items, in addition to all the demolition costs being offset, Party B still needs to pay Party A RMB. The payment shall be made in one lump sum on the signing date of this contract.

6. In order to ensure the construction quality, when signing the contract, Party B needs to pay a deposit of 20_yuan to Party A, which will be returned to Party B after the completion acceptance.

7. If there are any unsatisfactory matters during the performance of this contract, the two parties will negotiate and resolve them separately.

8. If there is a breach of contract in this contract, the breaching party shall pay liquidated damages of 5,000 yuan to the non-breaching party.

9. This contract will take effect after both parties seal and sign it. Don’t ignore the precautions in the decoration contract. Party A and Party B each hold one copy.

Party A (official seal): _________

Party B (official seal): _________

Legal representative (signature): _________

Legal Representative (signing the decoration contract): _________

___________month____________year____month______Factory Building Demolition Contract Part 4

Party A:

Party B:

After qualification review, Party A plans to have Party B carry out the house demolition project in the designated plot. In order to clarify the responsibilities and obligations of both parties, a house demolition agreement has been signed. The contract is as follows:

1. Demolition scope: 30 bungalows on the south side of the courtyard

2. Demolition period: The demolition period is 10 days. The specific demolition date will be determined by telephone and written notification. If the demolition period exceeds the specified time, a fine of 1,000 yuan will be calculated for each day of delay.

3. Demolition standards: The demolished buildings should be cleared to the foundation, the ground inside the house (cement floor) should be cleared, and all demolition garbage should be removed. Finally, the construction site was leveled, garbage was emptied, and restored to its original appearance.

IV. In this house demolition project, Party B must do the following:

1. Submit Party A’s management, actively cooperate with Party A’s work, and shall not transfer or subcontract the project in any form .

2. The designated main person in charge and the person in charge of the site shall not be changed at will. If changes are really necessary, Party A’s consent must be obtained.

3. Strictly abide by the safety management regulations for house demolition projects formulated by relevant superior departments, ensure safety responsibilities are in place, and carry out civilized construction. All safety responsibilities during construction are the responsibility of Party B and have nothing to do with Party A.

4. Take safety precautions when demolishing a house, mark safety warning signs, and ensure the safety of buildings and people entering and exiting the surrounding demolished house. If an accident occurs, Party B shall bear all responsibilities.

5. During the construction process, construction workers are not allowed to take away things outside the demolition scope. If any behavior is taken away, Party B will be held responsible.

6. Party B must dismantle the dismantled parts in the factory at one time without leaving any future troubles.

5. Cost settlement: The old items removed from the house (doors, windows, sandalwood strips, steel beams, etc.) belong to Party B, and Party B’s demolition project costs will be calculated from the old items. According to the appraised value of the demolished items, in addition to all the demolition costs being offset, Party B still needs to pay Party A RMB. The payment shall be made in one lump sum on the signing date of this contract.

6. In order to ensure the construction quality, Party B needs to pay a deposit of 20xx yuan to Party A when signing the contract, which will be returned to Party B after the completion acceptance.

7. If there are any unsatisfactory matters during the performance of this contract, the two parties will negotiate and resolve them separately.

8. If there is a breach of contract in this contract, the breaching party shall pay liquidated damages of 5,000 yuan to the non-breaching party.

9. This contract will take effect after being stamped and signed by both parties. Party A and Party B each hold one copy.

Party A (official seal): _________

Party B (official seal): _________

Legal representative (signature): _________

Legal Representative (Signature): _________

_________month____day_________year____month____day

_________year____month____day Factory Building Demolition Contract Part 5

Party A:

Party B:

Due to the needs of Party A’s project, the construction part of the steel structure demolition project is now contracted to Party B. In order to clarify responsibilities, Party B is specially The following terms are entered into for both parties to abide by.

1. Project content

Party B is responsible for dismantling and landing some of the steel structures and equipment currently in the factory area. According to the details of "Party A's Reserved Steel List", Party B will transport them to the designated location, and the property rights It belongs to Party A, and the rest, including all building materials and equipment, belongs to Party B.

The scope of demolition involved in this project is the steel structure materials and indoor equipment, excluding any content outside the "part of the steel list retained by Party A" and the area designated by Party A. Party B is also responsible for the removal and transportation of construction waste materials, and the on-site cleanup to the ground. Party B must complete all the work content of the project and comply with the specification requirements.

2. Project Price

2.1. After negotiation between the two parties, the total price Party B should pay to Party A for the project is RMB. Yuan, the settlement time is the date when the contract is signed. This price takes into account the value of all waste materials, labor costs, freight, construction material costs, construction equipment costs and all urban management, sanitation, and landfill expenses related to garbage removal. , spoil yard and other related expenses, including liability compensation to Party A and third parties due to safety accidents in this project.

2.2. Compensation expenses: Party B promises to complete the demolition project in accordance with the requirements of the contract and will not charge for demolition. The fee and compensation for Party A will be RMB 0.00.

2.3. Payment method: Party B shall pay the full compensation fee to Party A within the day after the contract is signed, and Party A shall collect it. After receiving the payment, a receipt will be issued to Party B.

3. Project quality , gas, etc.). If any unknown cables or pipes are found during demolition, the construction should be stopped and necessary emergency measures should be taken, and the work should be reported to the relevant functional departments in a timely manner, and the construction can be resumed after handling. The project is in our unit's factory area, and Party B shall unconditionally obey Party A's inspection and strengthen on-site construction quality management. Party A has the right to change the construction team based on Party B's construction performance.

IV. Construction Period

Party B must have enough manpower and relevant equipment to enter the construction site, and must complete all project contents before the date of the year.

5. Deposit

Before Party B moves into the construction site. A deposit of RMB should be paid in advance as a commitment to the risks of this project. After the completion of the project, the deposit will be refunded if the inspection and acceptance are passed by both parties. If the garbage is not cleaned up and causes additional losses to Party A, the deposit will be deducted. .

6. Safety in production

Party B is responsible for the safety management of the construction site. If any safety accident occurs, Party B shall be solely responsible for it and Party A will not be held responsible.

Seven: Breach of Contract Clause

If Party B violates the terms of this contract during the construction process and fails to make corrections after being notified three times and causes serious losses to Party A, it will be deemed a substantial breach of contract and the contract will be automatically terminated. Party A will no longer refund the deposit. If Party B causes a safety accident during construction, the construction shall be stopped immediately. If the matter cannot be properly handled in time, the contract will be automatically terminated and Party B will be responsible for all liabilities.

8. This contract is made in quadruplicate, with each party holding two copies. It will take effect from the date of signing and will be invalidated after the project is completed and the payment is settled, unless the matter is resolved through negotiation.

Party A (official seal): _________

Party B (official seal): _________

Legal representative (signature): _________

Legal Representative (Signature): _________

_________month____day_________year____month____day

_________year____month____day Factory Building Demolition Contract Part 6

Party A:

Party B:

In accordance with the "Contract Law of the People's Republic of China" and other relevant legal provisions, in the spirit of equality, voluntariness, honesty and trustworthiness In principle, after negotiation between Party A and Party B, an agreement has been reached on the electronic version of the decoration contract template entrusted by Party A to Party B for the dismantling of the factory building project, as follows:

1. Project name

Bazhou City III Li Industrial Co., Ltd. 550 hot rolling workshop demolition project

2. Project content

1. Demolish the workshop building to the ground level and remove the leg columns. to the underground junction.

2. Dismantle the tracks, concrete traveling beams, marking lines, etc. in the workshop and material yard.

3. The dismantled steel structure materials, color plates, doors and windows, etc. are transported to the designated location in Party A’s yard. The construction waste, concrete corbels, and concrete driving beams are dismantled and transported to the outside of Party A’s yard.

3. Contracting method

Party B is responsible for all related costs such as labor costs, machinery costs, transportation costs, tool costs, and material costs used in the project.

4. Project price

1. The price for dismantling the factory building is 18 yuan per square meter, and the settlement is based on the actual construction area.

2. After the concrete corbels and concrete driving beams are removed, they will belong to Party B. Party A will no longer pay for the removal of these parts. Electronic version of the decoration contract template.

5. Payment and Receipt Method

The funds will be appropriated according to the progress of the project. After the completion of the project and Party A’s acceptance, the entire project payment will be paid.

6. Engineering Decoration Contract Quotation List Project Period

Construction will start on November 21, 20_ and be completed before December 10, 20_. The project period shall not exceed 20 days.

7. Safety Responsibility

Before construction, Party B shall conduct safety education for its construction personnel. During the construction process, Party A has the right to inspect Party B’s unsafe conditions of property and unsafe behaviors of people. Inspect, supervise, and issue rectification instructions. If a safety accident occurs to Party B, or if the project causes damage to Party A or a third party, Party B shall bear all the responsibilities.

8. Project acceptance

Party B shall apply for project completion acceptance, and Party A shall accept it in time. If you do not apply for acceptance or do not accept timely, the party responsible for the decoration contract shall bear the responsibility.

9. Liability for breach of contract

1. If a breach of contract occurs during the performance of this contract, the breaching party shall bear the corresponding breach of contract and compensate the other party for the economic losses caused

2. If the project is not completed within the time limit of the decoration contract during the project period, Party B shall pay liquidated damages of 10% of the total project price for each day of delay.

10. Other Agreements

1. If the completion of the project is delayed due to Party A’s reasons or natural disasters, the project deadline may be extended.

2. Unfinished matters such as decoration contract template and project changes must be agreed upon and confirmed by both parties before being implemented.

3. This contract will take effect after being signed by both parties.

Party A (official seal): _________ Party B (official seal): _________

Legal representative (signature): _________ Legal representative (signature): _________

_______year____month____day_________year____month____day Factory Building Demolition Contract Part 7

The contract-issuing party (hereinafter referred to as Party A): ______

Contractor (hereinafter referred to as Party B): ______

After on-site investigation and negotiation between Party A and Party B, and in compliance with the principles of equality, voluntariness, fairness and good faith, both parties have reached the following agreement regarding the steel structure demolition project. Agreement:

Article 1: Project Overview

The demolition project is located in the Linqu Comprehensive Middle School Construction Headquarters Office.

Article 2: Project Contracting Scope

Roof steel structure support, aluminum doors and windows.

Article 3: Construction Period

1. Contract Period:

2. Construction Start Date:

3. Completion Date:

p>

Article 4: Quality standards:

1. Party B must dismantle and ship the dismantled steel structure in accordance with Party A’s requirements.

2. Party B should carry out civilized construction and ensure safety protection;

Article 5: Project price and payment method

The project price shall be based on the demolition steel Structural materials will be deducted from the dismantling costs in one lump sum, and the total contract price is approximately: ______ yuan (the price includes labor costs, machinery, management fees, and personnel insurance.)

Article 6 Party A’s Responsibilities and obligations

Party A is responsible for the coordination and construction supervision of the dismantling of the steel structure;

Article 7: Party B’s responsibilities and obligations

1. After Party B enters the site , must obey the coordination and command of Party A’s management personnel;

2. Party B’s management personnel must make safety briefings to construction personnel before construction;

3. Party B must assign experienced full-time safety personnel Party B’s personnel shall supervise the safe demolition construction to ensure that the demolition construction is carried out in a safe state;

4. Party B’s personnel shall take strict safety protection measures and bear the responsibility for any failure due to their own inadequate safety measures

Responsibility for causing the accident and the resulting expenses;

Article 8: Contract disputes and solutions

1. If the two parties have a dispute, they should resolve it through friendly negotiation. If the negotiation fails, , should be submitted to the local labor arbitration department for ruling or the people of xxxx where the project is located for prosecution.

Article 9: Others

1. The contract shall take effect upon signature by both parties. The contract shall be in duplicate, with Party A and Party B each holding one copy.

If one party breaches the contract, the breaching party shall bear all responsibilities.

Party A: ______ Party B: ______

Agent’s signature: ______

______year______month______day______year_ Part 8 of the factory building demolition contract on _____month______

Party A: ______

Party B: ______

In accordance with the "Contract of the People's Republic of China and the People's Republic of China" "Law", "Construction Law of the People's Republic of China" and other relevant laws and administrative regulations. Following the principles of equality, voluntariness, fairness and good faith, the two parties reached a consensus on the demolition of the factory in Xinying Sanitary Ware Factory and entered into this agreement. This Agreement Contract.

1. Dismantling content

Nowadays, some parts (steel structures) within the factory of Xinying Sanitary Ware Co., Ltd. need to be dismantled. The dismantling of the steel structures is now contracted to Party B. Party B is responsible for dismantling and landing the steel structure of the factory building, and is responsible for clearing and transporting construction waste materials, and cleaning up the site to the ground.

Party B must complete all work content of the project and comply with national regulatory requirements.

2. Demolition price

After negotiation between the two parties, Party B will pay Party A ______ yuan per square meter. Calculated based on the actual factory volume, and the settlement will be upon signing of the contract

Date, a lump sum is paid before starting the demolition. This price has taken into account the value of all waste materials that Party B deserves. The demolition costs include labor costs, freight costs, material costs, equipment costs and all urban management, sanitation, landfills, spoil sites and other related costs related to garbage removal. It also includes Liability compensation to Party A and third parties due to safety accidents in this project. Party B promises to complete the demolition project in accordance with the requirements of the contract and will not charge any fees related to the demolition.

3. Payment method

After both parties check the on-site quantities, Party B will pay Party A the entire amount of the factory in one go, and then the demolition will begin.

4. Construction date

The construction date shall be set according to the requirements of Party A and the factory and in strict compliance with the relevant national safety production and construction conditions. Party B must have enough professionals and relevant safety equipment to enter the construction site and complete all demolition contents before ______.

5. Qualification requirements

Party B must have the qualifications for building (steel structure) demolition, and provide relevant copies with a red seal of the unit. Personnel entering the site must hold employment certificates, operation certificates, safety belts, labor protection shoes and other safety protective equipment, and hold the certificates when working. Equipment and vehicles must strictly comply with the relevant regulations of the national competent authorities.

6. Safety production

Party B is responsible for the safety management of the demolition site. If a safety accident occurs, all responsibilities will be borne by Party B, and Party A will not be held responsible. For illegal and illegal operations discovered during construction that violate production safety regulations, work should be stopped immediately for rectification, and construction can only be carried out after safety education.

Seven breach of contract clauses

If Party B violates the terms of this contract during the demolition process and cannot make corrections after being notified three times and causes serious losses to Party A, it will be deemed a substantial breach of contract. The contract is automatically terminated, Party B loses the qualification for demolition and is not allowed to claim compensation from Party A. If Party B causes a safety accident during construction, the construction shall be stopped immediately. If it cannot be properly handled in time, the contract will be automatically terminated and all responsibilities will be borne by Party B. Party B will lose the qualification to dismantle and shall not make any claim against Party A.

8. Others

This contract is made in four copies, with each party holding two copies. It will take effect from the date of signing. It expired after the demolition work was completed and the matter was not resolved through negotiation.

Representative of Party A: ______ Representative of Party B: ______

______year______month______day______year______month______day