Selected 8 project contract templates 2022

Project contract template 2022 1

Employer: (hereinafter referred to as Party A)

Contractor: (hereinafter referred to as Party B)

Part

Selected 8 project contract templates 2022

Project contract template 2022 1

Employer: (hereinafter referred to as Party A)

Contractor: (hereinafter referred to as Party B)

Party A and Party B, in accordance with the National Law of People's Republic of China (PRC), the Building Law of People's Republic of China (PRC) and other relevant laws, regulations and rules, and following the principles of moral equality, voluntariness, fairness, honesty and credibility, reached an agreement on the construction of the glass rain building project of Zhaodong Shuguang Driving School through consultation and concluded this contract.

I. Project name:.

Second, the project address:

Third, the way of contracting: contracting for work and materials (big package).

Fourth, the project content: point the glass rain.

V. Engineering materials:

1. frame: use 15mm and 10mm iron plates to make a special frame for glass rainproof awning, then remove rust and brush fluorocarbon paint.

2, lacing: special lacing for glass rain.

3. Glass: 8mm+8mm tempered laminated glass, which is installed on the main frame driver with a special point glass bracket.

Total contract price of intransitive verbs: (1.500 yuan) per square meter, about 66 square meters, totaling (99,000 yuan). Tie bars are cost-effective separately, not included in the total square meter cost. The final settlement shall be subject to the measured area.

7. Construction period: the construction period shall be completed within one month from the date of receiving the advance payment.

Eight. Payment method: after the contract is signed, the down payment is 10000 yuan. After the main frame steel plate enters the site,

Pay 30% of the project price, 30% after the installation of the main frame, 37% after the completion acceptance, and keep 3% of the quality deposit. (If there is no quality problem, the state stipulates that the quality deposit will be returned within one year).

Nine. Liability for breach of contract:

1. The contractor promises to the employer to carry out the construction according to this contract. During the construction period, if Party B causes shutdown or shortage of personnel, and the quality cannot meet the requirements specified in this contract, it must be reworked and restarted. The losses caused thereby shall be borne by Party B, and the construction period shall not be postponed.

2. The Employer promises to the Contractor to pay the contract price and the amount payable in accordance with the time limit and method agreed in this contract, and to perform all obligations agreed in this contract. As Party A fails to pay the project payment as agreed in this contract, Party B has the right to stop work and postpone the construction period. Party A shall bear the loss of personnel and machinery and the corresponding expenses arising therefrom, and pay liquidated damages before returning to work.

X. Matters not covered in this contract shall be settled by both parties through consultation. If negotiation fails, a lawsuit can be brought to Zhaodong People's Court.

XI。 This contract is made in duplicate, one for each party, and shall come into effect after being signed and sealed. I hope * * * will abide by it.

Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _

Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Project contract mode 2022 2

Party A: (hereinafter referred to as Party A) _ _ _ _ _ _ Party B: (hereinafter referred to as Party B) _ _ _ _ _ _ _

The total length of the water conservancy project of Party A's power station is 2,800 meters, and the two single projects must be completed before the end of 20 years. Now Party B voluntarily leads the team to request the construction, and the following contract terms are signed by both parties through consultation.

1. Party B shall limit the length of trench works to 500m and the retaining wall to 500m.

Second, the unit price of the ditch is calculated as per meter of 50 yuan, and the masonry retaining wall is calculated as per cubic meter 10 yuan.

Three. Party B completed the follow-up package of trench wall construction in five hundred.

4. Party A shall be responsible for providing cement, stone powder, flaky, angle plates, water, electricity, mixers and rickshaws for this project, and Party B shall set up sheds.

Verb (abbreviation of verb) settlement method: 100% will be paid after Wu Bai Rice is completed. During this period, Party A will pay the living expenses to Party B at any time, and Party A will deduct them in full at the time of settlement.

6. Party B shall bring his own brick knives, sensitive knives, hammers, quilts, vegetable pots, rice cookers, chopsticks and other daily necessities. The fare is 40 yuan, and the living expenses are 60 yuan for five days. Everyone brings 20 kilograms of rice from home, and Party A pays the living expenses five days after Party B's construction.

Seven, construction specifications:

1. During the construction, Party B will first build a slope protection wall with a height of 1.4m and a plane width of 50cm.

2. Then erect the corner guard, with the height of both sides being 1.4m, the width of the ditch mouth being 1.7m and the bottom being1.4m. In fact, it is a ditch with a narrow ditch mouth and three flat sides. If it is concave, in short, the construction should follow the on-site guidance of Party A's technicians, and anyone of Party B must obey the arrangement and guidance of Party A. ..

8. After Party B completes the above-mentioned two single projects, it will make payment on the second day after the acceptance of the project headquarters.

9. During Party B's construction, it is forbidden to play cards, gamble, drink, fight or steal at night or in rainy days. If something like this happens, causing economic losses, the consequences will be borne by the individual who happened to Party B, and Party A will not be held responsible.

X. For matters not covered in this contract, if it is found that there is a conflict with the terms of the contract during the construction process, Party A and Party B must settle it through consultation, and the addition, deletion or modification of the terms of the contract must be agreed by both parties. The supplementary terms of this contract have the same legal effect as the original contract terms.

XI。 This contract shall come into force as of the date of signature by both parties and shall be protected by law. This contract is made in triplicate, one for Party A, one for Party B and one for the Engineering Headquarters.

12. In the process of construction, Party B must put safety in production first. In case of accidental casualties, Party B shall take care of itself, and Party A shall not be responsible.

The signature of Party A's representative is as follows: _ _ _ _ _ _ _ _ _ _ _ _

The signature of Party B's representative is as follows: _ _ _ _ _ _ _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Project contract mode 2022 3

Both parties to this contract:

Entrusting unit (Party A):

Agency (Party B):

Date of signing the contract: year month day.

The entrusting party entrusts Party B to handle the tender matters, and according to the provisions of the Bidding Law of People's Republic of China (PRC) and relevant laws and regulations, both parties to the contract sign this contract through consultation.

I. Contents and forms of agency business:

Party A entrusts Party B to organize bidding activities for construction projects.

Project overview:

Scope of this tender: content of construction drawing.

1. bidding agent content: fill in the application form and prepare bidding documents (including pre-qualification documents); Examining the qualifications of bidders; Organize bidders to visit the site and answer questions; Organizing bid opening, bid evaluation and bid selection; Provide pre-bid consultation and other services;

2. Bidding agent form: invitation to bid.

Second, the working conditions and cooperation matters:

1, construction project planning permit, proof of the source of funds for construction projects, etc. (For details, please refer to 1 List of Materials to be Submitted in Construction Project Bidding).

2. The entrusting party shall provide construction drawings and technical data that can meet the requirements of construction and valuation.

3. In the process of agency, Party B shall abide by the national and local laws and regulations on project construction bidding, adhere to the principles of openness, fairness, impartiality, honesty and credibility, follow relevant procedures, and accept the supervision of the bidding supervision and management department.

4. When signing this contract, the entrusted agent shall issue a certificate of entrustment.

Three. Entrustment period:

This contract shall be implemented from the date of signing, and will be automatically abolished after the bid-winning notice is issued.

Four. Payment method and date:

The project cost is RMB (in words), and the total agency fee is RMB (in words). The payment method is cash or transfer, and all expenses will be paid in one lump sum when the bid-winning notice is issued. Party A can choose to pay RMB in one lump sum or only according to the work completed by Party B, and Party B has no objection.

Verb (abbreviation of verb) liability for breach of contract:

1. Both parties must strictly abide by the terms of the signed agency contract and shall not breach the contract;

2. The entrusting party shall provide true and reliable relevant information and pay the agency fee according to the agreement in Paragraph 4, otherwise all responsibilities shall be borne by the entrusting party.

3. Disputes arising from the execution of this contract can be settled through negotiation or mediated by relevant departments.

4. When the terms of the agency contract are changed, both parties must sign a supplementary contract. As a part of the agency contract, the supplementary contract has the same legal effect as the main contract.

5. This contract is made in triplicate, one for Party A, one for Party B and one for the bidding management agency.

Other terms agreed by both parties of intransitive verbs.

Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _

Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Project contract mode 2022 4

Owner (Party A): Guiyang Hui Jin Electric Power Industry Company.

Contractor (Party B): Ye Zheng Electrical Installation Engineering Co., Ltd., Zunyi City, Guizhou Province.

Article 1 Contract Basis

The legal basis of this contract is the Contract Law of People's Republic of China (PRC) and the Construction and Installation Contract and Construction Regulations. The contents and quantities of this project are calculated and approved according to the construction drawing of the new electrical part of Qingzhen Hanpoling 1 10kv substation, Volume 1, Volume 6, Lighting and Volume 1, Volume 7, Lightning Protection and Grounding designed by Guizhou Nengda Electric Power Design Co., Ltd.

Article 2 Name, location, scope and content of the project

1. Project name: qingzhen city Hanpoling 1 10kv substation grounding and lighting installation project.

2. Project location: qingzhen city Hanpoling 1 10kv substation.

Three. Scope and content of the project:

1: lightning protection and grounding installation of Hanpoling 1 10kv substation in Qingzhen.

2. Lighting installation of Hanpoling 1 10kv substation in Qingzhen.

Article 3 Method of Contract

In this project, Party A will contract the project to Party B for construction, and the contracted materials will be settled by%. (The settlement amount adopts the 20xx annual price list in Beijing; The budget price of installation materials is in accordance with the Notice of Guizhou Electric Power Company on Guizhou Electric Power Company (20xx annual price); The cost composition shall be in accordance with the Management System and Regulations for Capital Construction Budget of Electric Power Industry (20xx Edition); According to the power technology of Guizhou Electric Power Company [20xx year.

Article 4 Cooperation between the two parties

Party A is responsible for:

One: Party A is responsible for coordinating the contact between the project and relevant units to ensure the construction progress of the project.

Party A shall timely organize relevant departments to conduct intermediate acceptance according to Party B's construction progress and concealment.

Party B is responsible for:

1. If Party B finds any problems during the construction, it shall promptly report them to Party A..

2. Party B shall complete all the work in the project on time, and shall not affect other projects.

Three. Completion data shall be submitted to relevant departments for review.

Article 5 Liability for breach of contract

Investigate the other party's liability for breach of contract according to relevant national laws and regulations.

Article 6 Ways of handling economic disputes.

If there is any economic dispute, both parties shall settle it through consultation based on the principle of seeking truth from facts. If they can't achieve their goal, they can apply to the people's court for arbitration.

Article 7 Construction period

This project has been completed before.

Article 8 Project contracting methods

The contract price of this project is the cost of labor, machinery, auxiliary materials and main materials.

Article 9 Safety responsibilities

Party B shall be responsible for the safety during the construction period and independently bear the corresponding responsibilities.

Article 10 Project cost

Project cost of this project: one hundred and twenty-nine thousand seven hundred and sixty Yuan only (129760.00), and the contract and materials of this project are settled according to the facts.

Article 11 number of contract copies

The original of this contract is in duplicate, each party holds 1 copy.

Article 12 This contract shall come into effect after being signed and sealed by the representatives of both parties.

Party A: (official seal) Party B:

Person in charge: (signature) Person in charge: (signature)

Date: Year Month Day Date: Year Month Day

Project contract mode 2022 5

Entrusting unit: (official seal)

(Party A)

Handler: (official seal)

(Party B)

Date of contract signing:

Both parties to this contract:

Entrusting unit (Party A):

Agent (Party B): The entrusting party of Haikou Chengjian Engineering Bidding Agency Co., Ltd. entrusts Party B to bid on _ _ _ _ _ _ _ _ _ _ _ _ _.

I. Contents and forms of agency business:

Party A entrusts Party B to organize bidding activities for construction projects.

Project overview:

Scope of this tender:

1. bidding agent content: fill in the application form and prepare bidding documents (including pre-qualification documents); Examining the qualifications of bidders; Organize bidders to visit the site and answer questions; Organizing bid opening, bid evaluation and bid selection; Provide pre-bid consultation and other services.

2, the form of bidding agency:

Second, the working conditions and cooperation matters:

1, temporary permit for construction project planning, proof of source of funds for construction projects, etc. (For details, please refer to the List of Materials to be Submitted in Construction Project Bidding).

2. The entrusting party shall provide construction drawings and technical data that can meet the requirements of construction and valuation; Or the construction project investment budget prepared by a qualified engineering cost consulting agency.

3. In the process of agency, Party B shall abide by the national and local laws and regulations on project construction bidding, adhere to the principles of openness, fairness, impartiality, honesty and credibility, follow relevant procedures, and accept the supervision of the bidding supervision and management department.

4. When signing this contract, the entrusted agent shall issue a certificate of entrustment.

Three. Entrustment period:

This contract shall be implemented from the date of signing, and will be automatically abolished after the bid-winning notice is issued.

Four. Payment method and date:

1. The project cost is RMB (in words) and the agency fee is RMB (in words). The payment method is cash or transfer, and the agency fee should be paid in full before the bid opening. Agency fee does not include pre-tender estimate preparation fee, pre-qualification fee and bid evaluation expert fee.

2. The cost of each tender purchased by the bidder is RMB (in words), and the income will be returned to Party B. ..

Verb (abbreviation of verb) liability for breach of contract:

1. Both parties must strictly abide by the terms of the signed agency contract and shall not breach the contract;

2. The entrusting party shall provide true and reliable relevant information and pay the agency fee in accordance with Paragraph 4 of Article 1, otherwise all responsibilities shall be borne by the entrusting party.

3. Disputes arising from the execution of this contract can be settled through negotiation or mediated by relevant departments.

4. When the terms of the agency contract are changed, both parties must sign a supplementary contract. As a part of the agency contract, the supplementary contract has the same legal effect as the main contract.

5. This contract is made in triplicate, one for Party A, one for Party B and one for the bidding management agency.

Other terms agreed by both parties of intransitive verbs:

Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _

Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Project contract mode 2022 6

Project Employer: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ (hereinafter referred to as Party A) Project Contractor: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _. The two sides reached the following agreement on the specific matters of contracting _ _ _ _ _ _ waterproof project:

1. Party A entrusts the above waterproof project to Party B for construction. The project is located in _ _ _ _ _ _ _ _ _ _

2. Party A entrusts _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

3. Before construction, Party B shall submit the construction organization design and project progress plan to Party A for review and approval. Party A shall ensure that the site has the construction conditions before Party B can carry out the construction. The construction period shall be within the reasonable time required by Party A, and Party B shall ensure that it is completed. Unless it rains or cannot work, Party A agrees to postpone it. Otherwise, Party A will delay the construction period and be willing to bear any punishment from Party A. During the construction period, Party B shall be responsible for it and bear the safety consequences not caused by Party A.. ..

4. Before the construction, Party B shall submit _ _ _ _ _ _ _ copies of relevant construction materials to Party A, and carry out the construction according to the construction specifications, so as to ensure that the leakage caused by the quality problems of waterproof works can be repaired within _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

5. After the project is completed, Party B shall provide Party A with an application report for completion acceptance, a bill of quantities calculation and a list of project settlement. Party A shall organize the project acceptance within _ _ _ _ days, and calculate the quantities and expenses. If the project is deemed to meet the specification requirements after the deadline, Party B's report and statement will be accepted, and Party A will pay the project cost according to the expenses stated by Party B..

The project cost agreed by Party A and Party B is calculated as _ _ _ _ _ _ _ _ _ _, and the total cost is about _ _ _ _ _ _ _ _ _ _.

Seven. Both parties agree on the payment method of this project:

Eight. Other agreed matters: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

9. Disputes arising from the performance of this contract shall be settled through negotiation by both parties or through mediation by the local administrative department for industry and commerce; If negotiation or mediation fails, it may apply to the Municipal Arbitration Commission for arbitration or bring a lawsuit to the people's court according to law.

X this contract is signed on _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party B (official seal): _ _ _ _ Legal representative (signature): _ _ _ _ _

Legal representative (signature): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Project contract mode 2022 7

Party A (consignor): Party B (carrier): Party A (consignor): Party B (carrier): Party B.

According to the Contract Law of People's Republic of China (PRC) and other relevant national laws and regulations, Party A and Party B have reached the following agreement through friendly negotiation on the principle of equality and mutual benefit, and both parties promise to guarantee the implementation of this agreement.

Article 1 Scope of cooperation: Party A entrusts Party B to transport the goods from the place of departure designated by Party A to the destination.

Article 2 Service requirements

1. Party B shall timely dispatch vehicles to transport Party A's goods according to Party A's demand for transporting goods, and the vehicle condition shall meet the safety requirements for long-distance transportation of Party A's goods.

2. Party B shall do its best to deliver the goods to the destination according to the time, place and consignee specified by Party A. ..

Article 3 Determination and payment of transportation price

1, transportation price: confirm the freight before each transportation.

2. The freight settlement cycle is _ _ _ days per month, that is, the freight incurred in the current month will be settled in the next month.

3. Payment method: transfer

Article 4 Contract Limitation and Dispute Resolution

1. The contract shall be valid from _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

2. This contract was signed on _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

3. For matters not covered in this contract, both parties shall sign a supplementary agreement after negotiation, which shall be regarded as a necessary supplement to this contract after confirmation and have the same effect as this contract.

Party A: _ _ _ _ _ _ _ _ _ _ Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Party B.

Representative: _ _ _ _ _ _ _ _ _ _ _ Representative: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Signing place: _ _ _ _ _ _ _ _ _ _ _ Signing place: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Date of Signing: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Project contract mode 2022 8

Through negotiation between both parties, Party A agrees to contract the demolition of the silo in the old reconstruction project of Xinyang Road 292 Flour Factory to Party B.. In accordance with the relevant provisions of the Economic Contract Law of the People's Republic of China and national laws, and in order to clarify the relevant responsibilities, rights and obligations of both parties, the following terms of this agreement are hereby signed and abided by both parties.

1. Project Name: Blasting Demolition Project of Vertical Bunker in No.292 Flour Mill, Xinyang Road

2. Project Location: Flour Mill, No.292 Xinyang Road

Three. Scope and content of project contracting:

1, according to the blasting scope and demolition sequence arranged by Party A. ..

2. Blasting demolition includes: charging, laying initiation network, alert initiation, post-explosion inspection, crushing concrete blocks larger than 50 cm and unexposed reinforced concrete parts.

3, all blasting engineering approval procedures.

4, completes the erection of safety fence, and meet the acceptance requirements.

4. Engineering quantity: According to the actual engineering quantity.

Verb (abbreviation of verb) settlement method: according to the actual quantity, the total price is 65,438+065,438+020xxx Yuan, which shall be paid to Party B after tax deduction.

Duration of intransitive verbs: days

Seven. Construction requirements: In order to ensure safe and rapid construction, the reinforcement and concrete blocks are basically separated after blasting, which meets the requirements of Party A, the supervisor and the owner.

Eight. Responsibilities of both parties:

(I) Party A's responsibilities

1. Assist Party B to handle the relevant blasting approval procedures and coordinate the relationship between the owners of the construction unit on the construction site;

2. Be responsible for providing Party B with two construction rooms as the assembly point for Party B's construction materials, rest and blasting of construction personnel;

3, responsible for providing construction related drawings;

4. Be responsible for Party B's safety protection according to the plan and regulations before blasting, and rectify those that do not meet the regulations and procedures;

5. During the blasting construction, assist Party B to evacuate the personnel within the warning range (including Party A's construction personnel and on-site living quarters);

6. Be responsible for providing Party B with electricity for construction.

(II) Party B's responsibilities

1. Party B must carry out the whole blasting demolition work with "safety first", strictly implement the "Blasting Safety Regulations" gb6722-20xx and the national, provincial and municipal standards and regulations on blasting engineering safety, rectify those that do not meet the regulations and rules, and conduct blasting only after careful inspection and acceptance;

2. Be responsible for preparing the blasting design scheme and handling the blasting related examination and approval procedures, coordinating the work of public security, traffic police and other departments, and bearing all expenses (including blasting safety assessment expenses);

3. When Party A cuts steel bars by gas, Party B will send safety personnel to supervise the whole process;

4. Responsible for the procurement, storage, transportation to the construction site, recovery and safety protection of initiating explosive devices, and bear the necessary expenses and corresponding safety responsibilities;

5. In the process of blasting, if people, houses and vehicles outside the warning range are injured or damaged due to the vibration of blasting flying stones, Party A shall bear all safety responsibilities (including economy), which has nothing to do with Party A;

6. Party B must undertake all the work of blasting safety warning, especially the setting of warning line before blasting and the evacuation of people around the blasting site. In case of safety accidents caused by Party B's insecurity, all responsibilities (including economy) shall be borne by Party B itself;

7. In order to meet the requirements of the owner, supervisor and Party A, Party B shall bear the penalties imposed on Party A by the owner, supervisor and competent department for blasting, protection and other reasons, and has the right to suspend the payment of the project funds.

Nine. This contract shall come into effect after being signed and sealed by the representatives of both parties. If there is any dispute, it shall be settled by both parties through consultation; If negotiation fails, it shall be settled by the people's court.

X this contract is in quadruplicate, with party a holding two copies and party b holding two copies. It will take effect after being signed and sealed by both parties, and will automatically become invalid after the project payment is settled.

Party A: Signature of legal representative (or entrusted agent): Date: MM DD YY.

Party B: Signature of legal representative (or entrusted agent): date: year month day.