Simple houses construction contract

Simple House Construction Contract 1 Party A:

Party B:

Due to the need of work, Party A reached the following agreement on the construction of a number of temporary board houses through friendly negotiation with Party B..

1. Project overview: The temporary construction site is located in the south of xx and east of xx, and the number of people is tentatively set at 200. The actual settlement shall be subject to the requirements of Party A and the actual number of construction rooms.

2. Responsibilities of both parties: Party A is responsible for the foundation treatment and ground hardening of the temporary house, and Party B is responsible for the construction of the above-ground buildings and the installation of doors and windows.

3. Building structure

The size of a single room is generally 3m× 5m, and the specific size and layout of the room shall be subject to the drawings provided by Party A.. ..

Two-story brick-concrete structure on the foundation; Wooden doors and windows, the glass thickness of doors and windows is not less than1cm; Poplar purlins are covered with reed foil and linoleum; Asbestos tiles shall be used for the walls, the thickness shall be not less than 5cm, and the price shall be not less than 4 yuan/block (subject to the current market price).

4. Time limit: Party B shall complete the construction of all houses within 15 days after receiving the construction site where Party A has completed the foundation treatment.

5. Price and settlement method: Party B will contract for materials, with asbestos tile house on the first floor in 530 yuan and asbestos tile house on the second floor in 660 yuan. After accepting the house delivered by Party B on schedule, Party A will settle 95% of the project payment with Party B, and the remaining 5% will be used as the security deposit. If there is no quality problem, it will be paid after the project is completed 1 year.

6. Liability for breach of contract: If Party B fails to complete the project on time, Party A has the right to deduct the construction project payment according to the loss. When the house has quality problems within 65,438+0 years, Party A may deduct the warranty money as agreed.

7. This Agreement is made in triplicate, with Party A holding two copies and Party B holding one copy.

8. This agreement shall come into effect after being signed and sealed by both parties. Matters not covered in this agreement shall be settled by both parties through consultation.

Party A: Seal

Party B: Seal

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Owner of simple houses Construction Contract 2 (Party A):

Contractor (Party B):

According to the Civil Code of People's Republic of China (PRC), the Building Law and the specific conditions of this house construction project, Party A contracts the woodworking project of its own house construction project to Party B.. In order to clarify the rights and obligations of both parties, this contract is signed by both parties through consultation.

1. Building engineering: Woodworking in private residential building engineering (first floor, first floor)

2. Construction site: Group 2, Longdong Village, Dawo Town

Third, the construction method and construction preparation

1. Party A contracts the woodworking project of its residential building to Party B in the form of a contractor.

2. Party B shall provide all tools needed for the construction and be responsible for all materials needed for carpentry in the construction project.

Four, the construction price is calculated by 30 yuan per meter, and the flat floor is calculated by 20 yuan per square meter.

Verb (abbreviation of verb) Party A requires that Party B be responsible for the transformation of the bottom girder. Any dispute between Party A and Party B during the performance of this contract shall be settled through patient negotiation. If negotiation fails, both parties agree to submit it to the Labor Arbitration Commission for arbitration.

Safety responsibility of intransitive verb: Party B shall take full responsibility for all safety accidents during construction.

Seven. Entry into force and termination of contract

1. This contract is made in duplicate, with each party holding one copy.

2. This contract shall come into effect as of the date of signature by both parties.

3. After the project is completed and accepted, when Party B delivers the house to Party A, Party A will pay off all the project funds.

Seven, the above contract, both parties must abide by * * *. If there are matters not covered, a supplementary contract can be signed by both parties through consultation, and the supplementary contract has the same legal effect as this contract.

Party A (official seal): _ _ _ _

Legal representative (signature): _ _ _ _

Party B (official seal): _ _ _ _

Legal representative (signature): _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Employer of simple houses Construction Contract 3 (Party A):

Contractor (Party B):

Party A has an existing private residence in _ _ _ _ _.

I. Project Structure: This project is a _ _ _ _ _ _ _ _

Second, the project contracting method: this project is a single package project, that is, Party A is responsible for providing all materials in the construction process, and Party B is responsible for the project construction and providing all construction tools and mechanical templates;

3. Project contracting unit price: the project is _ _ _ _ _ _ yuan/square meter according to the construction area;

Four. Project construction site: _ _ Project construction site: _ _ Project construction site: _ _ Project construction site

5. Project quality requirements: Party B must carry out the construction according to the construction drawings provided by Party A, and the imperfect parts of the construction drawings shall be constructed according to Party A's requirements, and embedded pipelines such as water, electricity, telephone and network shall be installed and embedded. During the construction process, Party B must supervise the engineering quality of Party A and complete all projects with good quality and quantity.

VI. Contents of the Project:

1. Main works: including plastering of internal and external walls;

2. Stick wall tiles, indoor floor tiles and stair tread tiles in front of the outdoor wall;

Seven. Party A's responsibilities: Party A is responsible for all coordination work and the provision of various building materials in the construction process, and Party A shall be responsible for the delay of Party B's construction period caused thereby.

Eight. Responsibility of Party B: Party B is responsible for the quality and quantity of all projects; Party B must follow the instructions.

Working drawings, Party A's requirements, relevant building construction drawings and Party A's requirements should be standardized, and all projects should be completed with good quality and quantity. If Party B makes mistakes in the construction project, Party B shall be responsible for the loss of building materials and working hours.

Nine. Receiving method: The receiving method of this project is to receive the building area of each floor, the staircase is 1.5 times of the projected area, and the closed balcony is 1 times.

X. payment method: _ _ _ _ payment method: _ _ _ _ payment method

XI。 Time limit: Party B must complete all the projects provided by Party A on time with good quality and quantity within 6 months (that is, within half a year);

Twelve. Safety responsibility: Party B shall be responsible for the safety accidents of Party B's personnel during the construction period.

Thirteen. For matters not covered in this contract, Party A and Party B shall separately formulate supplementary clauses, which have the same effect as this contract.

Fourteen This contract is made in duplicate, one for each party;

15. This contract shall come into effect as of the date of signature by both parties, and shall automatically become invalid after the project is completed and all payments are settled;

Sixteen, if both parties breach the contract, resulting in economic losses, the breaching party shall compensate twice the total loss.

Signature of Party A:

Signature of Party B:

Date:

Simple houses Construction Contract 4 Party A (Employer): _ _ _ _ _ _

Party B (contractor): _ _ _ _ _ _

Based on the principles of equality, voluntariness, honesty and compensation, Party A and Party B have reached the following terms of the agreement through repeated consultations in accordance with the provisions of relevant national laws and regulations for common compliance.

I. Name and location of the project:

xxxxxx

Second, the way of contracting:

Full contracting, the main body (excluding decoration) is the contractor's material foundation and the demolition of the old house, and the demolition materials of the old house are owned by Party B..

Third, the project contract price:

The total construction area of this project is about _ _ _ _ _ _ square meters (the exact area is calculated according to the projected area, subject to the actual area at the time of acceptance), and the contract price is RMB _ _ _ _ _ _ yuan per square meter. The roof and foundation are half stories each, and the demolition of old houses is not separately priced.

Four. Payment method:

Pay _ _ _ _% of the total amount after the foundation is completed, _ _ _% of the total amount when the transfer floor is completed, _ _ _% of the total amount when the main body of each floor is completed, and _ _ _% of the total amount after the main body of the general project is completed, and the remaining project funds will be paid within _ _ _ months after deducting the down payment when the house is delivered and accepted.

V. Project duration:

The construction period is _ _ _ months and will be completed before the end of _ _ _.

Six, safety responsibility:

Party B must strictly abide by relevant national safety laws and regulations and strictly abide by safety regulations. All safety responsibilities of this project shall be borne by Party B. Party A shall pay Party B a one-time safety fee of RMB in words only.

Seven, quality requirements and housing facilities:

1. On the sixth and first floors of the house, tiles are pasted on the facade, floor tiles are pasted on the pillars of the shop, and other surfaces are rubbed with cement. The height of the first floor of the house is 4.2 meters, and the height of other floors is 2.8 meters. Within 80 cm from the sky.

2. The building structure is brick-concrete structure, and the columns, main beams and load-bearing beams must be constructed in accordance with relevant national regulations and Party A's requirements, and the quantity of cement mortar on other floors shall not be less than 70 according to the conventional construction in Zhou Jia.

3. If the foundation is too deep and the pile exceeds 8m, Party B will be paid RMB/m for the excess ... The pipe fittings below the transfer floor shall not be less than RMB/root, and the septic tank shall be priced separately.

4. Housing facilities: each suite is equipped with a security door, the price is not less than RMB _ _ _ _ _ _, and the installation price of outdoor aluminum alloy windows is not less than RMB _ _ _ _ _ per square meter. Above, as well as the gap between the sewer and the floor, the cast-in-place slabs of the kitchen and bathroom are all within the scope of contracting.

5. The roof is a green tile roof, the diagonal distance between purlins is 70cm, and the diameter of the ends of purlins shall not be less than 8 cents.

6. Party B is not responsible for rolling doors, water, electricity, air stairs, handrails, outdoor and railings.

Eight. Rights and obligations of both parties:

(I) Rights and obligations of Party A

1. Party A appoints representatives to supervise and manage the quality, safety, progress and civilized construction of this project, and coordinate and manage related matters of the project construction.

2. Party A has the right to supervise Party B's engineering quality (especially concealed works), and to formulate quality and safety management measures and put forward suggestions and rectification opinions.

3. Have the right to supervise all kinds of building materials used by Party B, and prohibit unqualified finished and semi-finished materials from being used in this project, otherwise have the right to order them to be dismantled and replaced.

4. Have the right to supervise the civilized construction and safe production of Party B, ask Party B to rectify the problems existing in Party B, and have the right to deal with those who refuse to rectify or fail to rectify.

5. Party A has the right to impose a certain fine on Party B's bad behavior of being irresponsible for the project quality, as well as the behavior of serious illegal operation that is still not corrected after repeated warnings.

6. Have the right to supervise Party B to pay workers' wages in full and on time.

7. Party A is responsible for the road leveling foundation of this project, namely "three links and one leveling". If Party B stops working, Party A shall pay the wages of Party B's workers as usual and pay the water and electricity fee of RMB/day.

(II) Rights and obligations of Party B

1. Party B must carry out the construction according to Party A's requirements and install the outdoor doors and windows of the suite. In case of quality problems, Party B shall bear all economic responsibilities.

2. Party B is solely responsible for the mechanical equipment and its installation required for construction, the procurement and transportation of bricks, cement, steel, river sand and gravel, and the organization, management and arrangement of technicians and handyman.

3. Party B must do a good job in safety management. Party B is responsible for the implementation of safety measures, the setting, installation and wearing of safety racks, safety nets, safety helmets and safety belts, and accepts the supervision of Party A or relevant law enforcement departments. In case of safety accident, all expenses shall be borne by Party B and corresponding responsibilities shall be borne.

4. Party B has the right to ask Party A to pay according to the progress of the project, that is, as stipulated in Article 4 of this contract.

5. Party B shall dispose of the construction waste by itself and bear all expenses.

6. Party B shall complete the project on time, with good quality and quantity as required by Party A, and shall not delay the construction period without reason (except for force majeure factors). If the project is completed on schedule and passes the acceptance, Party A will reward Party B with RMB _ _ _ _ _ _ _ _ _ _.

7. Party B voluntarily provides a quality deposit of 3% of the total project cost, calculated from the date of completion. If there is no quality problem within two years, Party A will return the deposit in full.

Nine. Liability for breach of contract:

After this contract comes into effect, both parties shall not go back on their word. If one party violates this contract, it shall pay a penalty of RMB _ _ _ _ _ _ _.

X. Matters not covered in this contract shall be settled by both parties through consultation. This contract is the true intention of both parties, and there is no coercion, misunderstanding or violation of laws and regulations. It will take effect after being signed by both parties. This contract is made in duplicate, each of which has the same legal effect.

Party A: _ _ _ _ _ _

Party B: _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Simple houses Construction Contract 5 Owner (Party A):

Contractor (Party B):

In accordance with the relevant provisions of the Contract Law of People's Republic of China (PRC) and the Construction Law, and in combination with the specific conditions of this housing construction project, and in order to clarify the rights and obligations of both parties in the housing construction project, both parties entered into this contract through friendly negotiation on the premise of equality and voluntariness.

Article 1, project description.

The private house to be built by Party A is located at No.72, Commune Road, Jingchuan County, and it is planned to build two floors. The floor height is: 3.3m on the first floor and 3.0m on the second floor. The building area is about 290.52 square meters.

Article 2. Construction method and construction preparation.

1. Party A contracts the main works of the building (including bricklayer, steel bar worker and ancillary works) to Party B for construction according to the material-free contract mode.

2. Party A shall provide all the building materials needed for the housing project in time, and be responsible for the water and electricity supply on the construction site.

3. Party B shall bring all the equipment needed for the building, including construction machinery, such as trolleys, mixers, vibrators, cutting machines and tower cranes. Protective measures shall be taken in rainy days to prevent the overall quality of the project from being affected by rain.

Article 3. Construction cycle.

The project started on April 8, 20xx, and the whole project will be completed by the end of June at the latest. (Time is calculated by solar calendar)

Article 4. Project task, unit price and payment method:

1. The overall construction tasks are: foundation masonry, main works, indoor and outdoor wall painting, indoor and outdoor ground treatment, indoor and outdoor trench construction, water heating and reserved electric holes. Harden the surrounding area of the house, build a tap water observation well, and build a sewage sedimentation tank.

2. The building price is 265 yuan (two hundred and sixty-five yuan) per square meter according to the construction area, and the building edge and balcony are calculated as 132.5 yuan/square meter.

3. Payment method: the salary is 265 yuan per square meter, the total construction area is 290.52 square meters, and the total contract price is 76,987.8 yuan. Party A shall pay the total contract price in three installments. For the first time, after the foundation project is completed, Party A pays Party B ten thousand yuan (10000); For the second time, after the main project is completed, Party A shall pay Party B the total contract price of twenty thousand yuan (20xx0); For the third time, after the project is completely completed, Party A pays Party B the total contract price of 46,987 yuan.

Article 5. Rights and obligations of Party A and Party B

1. Rights and obligations of Party A:

(1) Party A provides Party B with "three links and one leveling".

(2) Pay on schedule.

(3) Provide all necessary materials to Party B in time.

(4) Before the project starts, Party B shall be provided with two sets of design drawings, and Party A shall provide construction guidance for the contents not indicated in the drawings, and Party B shall carry out the construction according to the guidance.

(5) In the process of construction, if quality problems are found or the design drawings are changed without authorization, Party A has the right to require Party B to rework.

2. Rights and obligations of Party B:

(1) Carry out the construction according to the drawings and Party A's requirements. If it is necessary to change the original design and Party A's requirements during the construction, it can only be modified with Party A's consent.

(2) Ensure the engineering quality.

(3) Ensure the construction period and finish the project on time.

(4) During the construction, Party B shall inform Party A of the materials needed 3-5 days in advance so as to purchase them in time. Party B shall adhere to the principle of economy and shall not waste materials.

(5) After each subdivisional work is completed, Party B shall obtain Party A's acceptance before proceeding to the next working procedure.

(6) Party B shall pay attention to production safety, and all safety responsibilities shall be borne by Party B. ..

(7) Any materials and unearthed objects on Party A's construction site belong to Party A, and Party B and construction personnel have no right to dispose of or take them away. Otherwise, Party A has the right to deal with the breach of contract, and Party B (the contractor) is responsible for restoring the original appearance, and Party A will not bear any negative impact.

Article 6, engineering quality requirements.

1. Party B's construction personnel must have certain construction experience to ensure that the project undertaken by Party B meets the relevant national norms and quality and technical evaluation standards. The quality of the project should meet the qualified conditions of the evaluation standard for earthquake-resistant buildings. After the completion of the building, the wall and the ground should be flat and free from hollowing, in line with relevant technical standards.

2. Party B shall carry out the construction according to the drawings and requirements provided by Party A.. If there are unreasonable and unclear parts in the drawings, Party B shall carry out the construction according to the scheme agreed by both parties through consultation. ..

3. If the project quality fails to meet the qualified conditions due to Party B's own reasons, Party B shall rework, modify and rework according to Party A's requirements, and bear the labor, materials and other expenses arising from rework, modification and rework. Party B shall be liable for breach of contract for engineering quality if it still fails to meet the agreed qualified conditions after rework and modification.

Article 7, construction safety requirements.

1. Party B must pay special attention to safe construction. Construction shall be carried out in strict accordance with safety construction specifications and technical requirements, and drunken operation is strictly prohibited. Take strict safety protection measures, control all possible dangerous factors, eliminate unsafe hidden dangers and prevent all accidents.

2. In order to ensure the safety of construction workers in case of emergency, Party B must buy safety insurance for the workers, and the expenses will be deducted from the wages. If an accident is caused by Party B's inadequate or ineffective safety measures, Party B shall bear the responsibility and all medical expenses arising therefrom. Party A has nothing to do with responsibilities and expenses.

Article 8. Liability for breach of contract and settlement of disputes.

1. If Party A fails to provide relevant information in time according to Party B's project progress, resulting in project shutdown, Party B will not be responsible.

2. If the project quality undertaken by Party B does not meet the agreed requirements, Party B shall repair, rework or redo it for free. Where material losses are caused, Party B shall be responsible for compensation.

3. Any dispute between Party A and Party B during the performance of this contract shall be settled through patient negotiation. If negotiation fails, both parties agree to submit it to the Labor Arbitration Commission for arbitration.

Article 9. Entry into force and termination of the contract.

1. This contract is made in triplicate, with each party holding one copy. Notary.

2. This contract shall come into effect as of the date of signing.

3. After the completion acceptance, Party B will deliver the project to Party A, and Party A will pay all the expenses, and this contract will terminate naturally.

Both parties must abide by the above contract. If both parties sign a supplementary contract through consultation, the supplementary contract has the same legal effect as this contract.

Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _

Legal representative (signature): _ _ _ _ Legal representative (signature): _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Simple House Construction Contract 6 Party A:

Party B:

Party A is building a house with a total construction area of about square meters, which will be contracted by Party B. Through consultation, both parties agree to sign the following contract:

First, the contracting method.

Take the way of contracting without contracted materials. Party A shall provide the materials needed for the building, and Party B shall provide labor services and construction technology.

Second, the construction project

Party B shall carry out the construction according to the design drawings or the requirements put forward by Party A. The buildings of Party A's main building project include walls, beams, columns, stairs, floors, formwork installation, formwork removal, steel bars, cast-in-place concrete and concrete cushion of the ground and front steps; Paint the interior roughly, paste the tiles on the front outer wall, brush cement mortar along the rear outer wall, paste the bathroom floor and wall tiles, and install porcelain pots, sewer pipes and downspouts; The top layer should be polished with cement slurry, and at the same time, it should be impervious and impervious.

Third, the contract price

RMB (in words:) per square meter, and the construction area is calculated according to the interior wall of each floor. The construction scope includes all the walls that need cement mortar plastering.

Four. mode of payment

Pay RMB yuan, pay RMB yuan, and the project is completed. Pay off the remaining amount in one lump sum after passing the acceptance.

Verb (abbreviation for verb) The responsibility of both parties.

1. Party A is responsible for water and electricity supply and raw material supply, and for the meals of Party B's construction personnel.

2. Party B must ensure the quality and progress of the project, carry out the construction according to the design drawings and Party A's requirements, save materials and take good care of them, and do not lose them.

3. In the process of building, if Party B's construction personnel suffer work-related injuries or other personnel are injured due to construction, Party B shall be responsible for everything, and Party A shall not bear any responsibilities and expenses.

Six, quality requirements

Party B shall organize the construction according to the housing quality standards and requirements stipulated by the state, and Party B shall be responsible for reworking the unqualified ones, and the rework expenses shall be borne by Party B. ..

Seven, the time limit for a project requirements

The construction period of the main project is: Party B must complete the main project before, and the completion time shall not exceed 65,438+00 days. Party B shall not delay the completion time of Party A's building for any reason. Party B shall submit the plan to Party A two days in advance for quick preparation.

Eight. any other business

1. Other matters not covered shall be settled by both parties through negotiation.

2. This contract is made in duplicate, one for each party, and shall come into effect as of the date of signature by both parties.

Party A: (signature) Party B: (signature)

Date: Date: